Loading...
HomeMy WebLinkAboutS Grant - Orange Community Housing and Land Trust Inc' Please return this copy to _• Clerk to the Boazd's office for PAF • NORTH CAROLINA ~1,1~~~ ORANGE COUNTY y' e GRANT AGREEMENT This is an AGREEMENT between ORANGE COiJNTY, NORTH CAROLINA, a general local governmental unit of the State of North Carolina, (hereinafter referred to as the "County") and Orange Community Housing and Land Trust, Inc., a North Carolina. non- profit c rpo • tion (hereinafter referred to as "OCHLT"). The effective date of this agreement is ~~ WITNESSETH WHEREAS, the Orange County Board of County Commissioners has designated $100,000 in Orange County Affordable Housing Bond funds for the purpose of acquiring a housing unit located at 113 Milton Avenue in Chapel Hill and hereafter referred to as the "Project" or the "project dwelling unit"; and WHEREAS, OCHLT intends to acquire and lease the project dwelling unit and thereafter demolish the dwelling unit and replace it with another unit for sale to a qualified • buyer, as described herein, to families earning up to 80% of HUD azea median income as described in the OCHLT Bond Program Application dated February 28, 2008 which Application is incorporated by reference into this Agreement. The February 28, 2008 Bond Program Application is on file in the office of the Orange County Department of Housing and Community Development. NOW, THEREFORE, in consideration of the mutual covenants, promises, and representations contained herein, it is agreed between the parties hereto as follows: 1. OCHLT agrees to acquire the project dwelling unit and lease it in the following manner a. OCHLT shall acquire the Properly including the Project dwelling unit and ensure that the unit meets the Section 8 Housing Quality Standards (HQS) prior to leasing. All repair work must be completed in accordance with applicable building and zoning ordinances and N.C. Housing Finance Agency Energy Standazds. b. OCHLT shall lease the project dwelling unit, as herein defined, to qualified tenants who live or work in Orange County and whose income is up to but no more than 80% of the area median household income by family size, as determined by the U.S. Department of Housing and Urban Development at the time of the rental. c. OCHLT shall later demolish the project dwelling unit and replace it with another unit for sale to a qualified buyer whose income is up to but no more than 80% of the area median household income by family size, as determined by the U.S. Department of • Housing and Urban Development at the time of the sale. OCHLT shall provide no less than 90 days notice to the current tenant prior to scheduled demolition of the project dwelling unit. d. The period of affordability will be at least 99 yeazs and is secured by a Declazation of Restrictive Covenants (Exhibit A) with restrictions to ensure compliance. e. OCHLT is responsible for verifying the income of prospective tenants and buyers and maintaining eligibility data.. OCHLT shall maintain tenant files as part of its Books and Records as required and for the period of time required by Section 6c.of this Agreement. OCHLT must provide the County an initial occupancy report verifying the income eligibility of all tenants at the time of initial lease-up. Further, OCHLT must furnish the County with an annual report on the Project dwelling unit by July 31 of each yeaz thereafter certifying that all tenants earn less than 80% of the azea median income by family size, as determined by the U.S. Department of Housing and Urban Development and as amended from time to time. 2. At the time of resale of the project dwelling unit, OCHLT will convey a housing unit to a qualified homebuyer. Each housing unit will consist of a 99 yeaz Ground Lease (renewable for an additional 99 years) to the project dwelling unit. The Ground Lease, the form of which is Exhibit C hereto, provides for the long term affordability (at least • 99 years) of the housing unit and provides remedies to insure the long term affordability of the housing unit. OCHLT hereby declares and covenants, on behalf of itself and all future owners of the Properly, that, during the term of this Declaration, the County is a third party beneficiary of and successor to each and every remedy intended to insure the long term affordability of the housing unit that is provided for in the Ground Lease and may, in the event of the failure or default of the Lessor in the Ground Lease to insure the long term affordability of the housing unit as provided for in the Ground Lease, exercise all rights and remedies available to the Lessor in the Ground Lease for that purpose. 3. Each housing unit must have a value that does not exceed 95% of the area median purchase price for that type of housing. Value must be established by one of the following methods: i. An appraisal by a qualified appraiser. ii. Tax assessments may be used to establish value, but only if they are current and can be computed at 100% of mazket value. 4. Time for Commencement and Completion. The Project must begin within six (6) months of the date of this Agreement. In addition, OCHLT agrees to furnish to the County a copy of its annual audit performed by a certified public accountant within 90 days of the end of each fiscal year until the Project is complete. • The Project completion date is the closing date of the conveyance of a dwelling umt 2 Ground Lease to a qualified buyer of the Project dwelling unit. In the event that OCHI,T is unable to proceed with any aspect of the project in a timely manner, and County and . OCHLT determine that reasonable extension(s) for completion will not remedy the situation, then the Termination of Agreement provisions of this Agreement (Section 6.a.) shall pertain. OCHLT may, at its option, submit a written request for a delay of completion for County approval. The County may, at its option, approve any delay in the completion date or declaze OCHI,T in default. OCHLT shall monitor the housing unit for affordability for the period of affordability - ninety-nine (99) years and, if renewed, an additional ninety-nine years. Final contract completion date shall be the end date of the last affordability period. 5. Affordability Requirement. Each housing unit must remain affordable for a period of ninety-nine years. OCHLT retains full responsibility for compliance with the affordability requirement for the assisted housing unit. OCHLT shall assure compliance with affordability of the assisted housing unit by having recorded, no later than the time it leases the project dwelling unit, a "Declazation of Restrictive Covenants" (Exhibit A) on the Property. This Declaration shall constitute and remain a first lien on the Property during the period of affordability, unless otherwise provided by law or unless otherwise agreed by County. It is further the responsibility of OCHLT to rerecord the Declaration of • Restrictive Covenants no later than one day before the expiration of 30 years of the date of its lease of the project dwelling unit. The County retains the right to periodically and every 30 yeazs after the first recording of the Declazation of Restrictive Covenants to register, with the Register of Deeds of Orange County, a notice of preservation of the restrictive covenants on the Property as provided in North Cazolina General Statute § 4713-4 or any comparable preservation law in effect at the time of the recording of the notice of preservation. It is the intent of this Section of this Agreement that the 99 year affordability requirement contained herein be accomplished and that OCHLT and the County will do what is necessary to ensure that the same is not extinguished by the Real Property Mazketable Title Act or any compazable law purporting to extinguish, by the passage of time, non possessory interests in real property. OCHI,T and the County agree to do what each must do to accomplish the 99 yeaz affordability requirement. 6. Miscellaneous Provisions. a. Termination of Agreement. The full benefit of the Project will be realized only after the completion of the affordability period for the project dwelling unit purchased under this Agreement. It is the County's intention that the full public benefit of the Project shall be completed under the auspices of OCHLT for the assisted housing units as follows: i. In the event that OCHLT is unable to proceed with any aspect of the Project in a • timely manner, and County and OCHLT determine that reasonable extension(s) for completion will not remedy the situation, then OCHLT will retain responsibility for 3 • requirements for any dwelling unit assisted and County will make no further payments to OCHLT. ii. In the event that OCHLT, prior to the contract completion date, is unable to continue to function due to, but, not limited to, dissolution or insolvency of the organization, its filing a petition for bankruptcy or similaz proceedings, or is adjudged bankrupt or fails to comply or perform with provisions of this agreement, then OCHLT shall, upon the County's request, convey to the County the project dwelling unit assisted with funds. Conveyance shall be at the sole discretion of County and on a dwelling unit by dwelling unit basis. Conveyance shall be on the terms set forth herein: Conveyance shall occur within thirty (30) days of County and OCHLT's agreement of OCHLT's inability to continue as a viable organization. OCHLT shall convey the Property to the County by general warranty deed, free and cleaz of all liens and encumbrances of record except those which create a beneficial interest in County (Declaration of Restrictive Covenants) and any other agreed to by County in writing. b. Default, Remedies. This Agreement may be terminated by anon-defaulting party upon an event of default hereunder, after written notice thereof and thirty (30) days grace • period in which the defaulting party may act to cure. As used herein, the term "an event of default" shall mean and refer to a failure or act of omission by either party with respect to any undertaking, obligation, covenant or condition as set forth in this Agreement. With respect to any event of default, the non-defaulting party may exercise any right available to it of law or in equity with respect to such default. c. Books and Records. OCHLT shall maintain records of its grant requirements under this contract for a period of not less than five (5) full fiscal yeazs following the contract completion date. i. OCHLT shall ensure access to records and financial statements, as necessary, to provide effective monitoring and evaluation of project performance. Additionally, OCHLT shall submit a copy of its annual audit to the County. Upon reasonable advance notice, County or its authorized representatives may from time to time inspect, audit, and make copies of any of OCHI,T records that relate to this contract. If any audit by County discloses that payments to OCHLT were in excess of the amount to which OCHLT was entitled under this contract, OCHLT shall promptly pay to County the amount of such excess. If the excess is greater than 1 % of the contract amount, OCHLT shall also reimburse County its reasonable costs incurred in performing the audit. • ii. OCHLT shall maintain files of all tenants residing in the assisted unit. Documentation shall verify eligibility for federal assisted housing at the initial 4 • occupancy. Information maintained shall include: tenant income level; name of family members; ethnic data; family type - e.g. female head of household and disability status. iii. OCHLT shall maintain records verifying the affordability of the dwelling units. d. Notices. Any Notice shall be in writing and shall be given by depositing the same in the United States mail, post-paid and registered or certified, and addressed to the party to be notified, with return-receipt requested, or by delivering the same in person to an officer or principal of such party. Notice deposited in the mail in the manner here in above described shall be effective upon mailing. For purposes of Notice, the addresses of the parties shall, unless changed as hereinafter provided, be as follows: i. To the County: Orange County c/o Housing and Community Development Department P.O. Box 8181 Hillsborough, NC 27278 ATTN: Director ii. To OCHLT: Orange Community Housing and Land Trust P.O. Box 307 • Carrboro, NC 27510 ATTN: Executive Director Either the County or OCHLT may change the person or address to which any future Notice shall be given as herein provided. e. No Assignment. No transfer or assignment of the interest of OCHLT in this Agreement shall occur without the prior written consent of the County; neither may OCHLT assign this Agreement without the prior written consent of County. f. Conflict of Interest. OCHLT agrees to abide by the provisions of 24 CFR 570.611 with respect to conflicts of interest, and covenants that it presently has no financial interest and shall acquire no financial interest, direct or indirect, that would conflict in any manner or degree with the performance of services required under this Agreement. O~HLT further covenants that in performance of this Agreement no person having such a financial interest shall be employed or retained by OCHLT hereunder. These conflicts of interest provisions apply to any person who is an employee, agent, consultant, or elected official or appointed official of the County, or any designated public agencies or subrecipients that are receiving funds under the Orange County Housing Bond Program. g. Binding Effect. This Agreement shall be binding upon and shall inure to the benefit of the parties hereto and their respective successors and assigns. • 5 • h. Indemnification. To the extent permitted by law, OCHLT shall indemnify and hold County, its officers, agents, and employees, harmless from and against any and all claims, actions, liabilities, costs, including attorney fees and other costs of defense, arising out of or in any way related to any act or failure to act by OCHLT, its employees, agents, officers, and contractors in connection with this contract. In the event any such action or claim is brought against County, OCHI,T shall, upon County's tender, defend the same at OCHLT' sole cost and expense, promptly satisfy any judgment adverse to County or to County and OCHLT jointly, and reimburse County for any loss, cost, damage, or expense, including attorney fees suffered or incurred by County. i. Subcontracting. OCHLT shall not subcontract work under this Agreement, in whole or in part, without the County's prior written approval. OCHLT shall require any approved subcontractor to agree, as to the portion subcontracted, to comply with all applicable federal, state, and local laws, rules, ordinances, .and regulations at all times and in the performance of the work and to comply with all applicable obligations of OCHLT specified in this contract. Notwithstanding County's approval of a subcontractor, OCHLT shall remain obligated for full performance of this contract and County shall incur no obligation to any subcontractor OCHLT shall indemnify, defend, and hold County harmless from all claims of its contractors. j. No Joint Venture or Agency. The County and OCHLT each agree and acknowledge that nothing contained herein or otherwise, including, without limitation, any act of the County or OCHLT under this Agreement, shall be deemed or construed to create any relationship of joint venture, partnership or agency between the parties. k. Effect of Waiver or Forbearance. No failure by the County to insist upon the strict performance of any term or condition of this Agreement, or to exercise any right or remedy upon the breach by OCHLT of any of its obligations, agreements, or covenants hereunder, shall be a waiver of such affected term or condition or of such breach; nor shall any forbearance by the County to seek a remedy for any breach by OCHLT be a waiver by the County of its rights and remedies with respect to that or any other breach. 1. Governing Law. This Agreement shall be construed in accordance with and. governed by the laws of the State of North Cazolina. Any litigation arising out of this Agreement shall be brought in courts sitting in North Cazolina, with venue in Orange County. m. Severability. The provisions of this Agreement aze independent of and sepazable from each other, and no provision shall be affected or rendered invalid or unenforceable by the fact that for any reason any other provision may be invalid or unenforceable in whole or in part. If any provision of this Agreement or the application thereof to any person or circumstances shall, to any extent, be or become invalid or unenforceable, the remainder of this Agreement, or the application of such provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each provision of this Agreement shall be valid and be enforced to the fullest extent permitted by law. The County and OCHLT agree to substitute for such provision of this Agreement or the 6 • application thereof determined to be invalid or unenforceable, such other provision as most closely approximates, in a lawful manner, such invalid, illegal or unenforceable provision. If the County and OCHLT cannot agree, they shall apply to a court of competent jurisdiction to substitute such provision as the court deems reasonable and judicially valid, legal and enforceable. Such provision determined by the court shall automatically be deemed part of this Agreement ab initio. n. Equal Opportunity. OCHLT shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, political affiliation or belief, age, handicap, or familial status in the implementation of the Project. o. Headings. Headings are for convenience only and shall not be used to interpret or construe its provision. p. Gender; Singular and Plural. As used herein, the neuter gender includes the feminine and masculine. The masculine includes the feminine and neuter, and the feminine includes the masculine and neuter and each includes a corporation, partnership or other legal entity when the context so requires. The singular number includes the plural and vice versa, whenever the context so requires. q. Recording. The parties hereto agree that upon notice to the other and at its own • cost and expense, a party may record this Agreement in the Office of Register of Deeds for Orange County. r. Compliance with Laws. To the extent applicable, each parry hereto agrees to comply with all laws, ordinances and regulations affecting the Property from and after the date hereof. Without limiting the generality of the foregoing, OCHLT shall comply with all federal, state and local laws, regulations and ordinances applicable to the expenditure of funds provided by the County, to purchase and develop the Property. s. Publicity; Signage. OCHLT agrees to provide such publicity with respect to the County's participation in the Project, as the County shall reasonably require. Any signage at the dwelling unit shall acknowledge the County's role and contribution. t. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original but all of which together shall constitute on and the same instrument. u. No Third Party Rights. The parties hereto covenant and agree that nothing contained in this Agreement or any act by the County or OCHLT shall be deemed or construed by the parties or any third parry to create any relationship of third party beneficiary, including third party principal or agent, or to create any right, claim or cause of action against the County, OCHLT or any of their respective officers, agents or employees by any third party. • 7 • v. Performance of Government Functions. Notwithstanding anything in this Agreement which may be to the contrary, nothing contained in this Agreement shall in any way stop, limit or impair the County from exercising or performing any regulatory, policing or governmental powers or functions with respect to the Property including, without limitation, inspection of the Property in the performance of such functions. • 8 • IN WITNESS WHEREOF, the parties hereto, intending to be legally bound, have set their hands and seals on the day and yeaz first above written. NGE COUNTY, NORTIi CAKULllVA ~~~~~~~~ i Blackmon, County Manager as to form • document has been preaudited in accordance with the N.C. Local Government and Fiscal Con ct. Gary Humphreys, Finance Director NOR CAROLINA ORANGE COUNTY instrument is the act and deed of Orange County. This is to certify that on this day personally came before me Donna Baker, with whom I am personally acquainted, and being by me duly sworn, says that Laura Blackmon is the County Manager of Orange County, North Carolina, and that she is the Clerk to the Boazd of Commissioners of Orange County, North Carolina, the body politic and corporate named within and which executed the foregoing instrument; that she. knows the common seal of said County; that the seal affixed to said instrument is said common seal; that the name of Orange County, North Cazolina was subscribed thereto by the said County Manager of Orange County, North Cazolina and said Donna Baker subscribed their names hereto and said common seal was affixed, all by order of the Boazd of County Commissioners of Orange County and that said Witness my hand and notarial seal, this the L/ .day of 2Q(J~ • My commission expires: /~ ~ ,DUC1 Notary Public 9 Clerk to the Board of Commissioners • Orange Community Housing and Land Trust, Inc. /'CE' Pr ident • NORTH CAROLINA ORANGE COUNTY I, ~ ~ ~ ,Notary Public in and for the above name County and State, do her by ce that on this day personally appeared before me ~ ' whom I am personally acquainted, who, being by me duly sworn, says that he is of Orange Community Housing and Land Trust, Inc, a North Carolina corporation, and that by authority duly given and as the act of the corporation, the foregoing instrument was signed by him on behalf of the corporation. Witness my hand My commission expires: 2(~ . ``` ~ ~ ~ ~ 1 t f 11111 / / / ~ ~ i ~~``~l''~ LYNNE ~~~~ ~GJ ~~,~~,~SSlp~y~o%~r~"~~i .~ .., ~ ~ ?c''• `f~~~~~TgRY pVe~~ ~``. ////p~11~i~U`~~, • 10 Exhibit A Prepared by and return to: Geoffrey E. Gledhill, P.O. Drawer 1529, Hillsborough, NC 27278 DECLARATION OF RESTRICTIVE COVENANTS • THIS DECLARATION OF RESTRICTIVE COVENANTS (Declazation), dated by Orange Community Housing and Land Trust, Inc, and its successors and assigns (Owner), is given as a condition precedent to the awazd of Orange County Housing Bond funds by Orange County, North Cazolina, a body politic and corporate, a political subdivision of the State of North Carolina, (hereafter "the County") together with any successor to its rights, duties, and obligations. RECITALS: WHEREAS, the Orange County Boazd of County Commissioners has designated $100,000 in Orange County Affordable Housing Bond funds for the purpose of acquiring a housing unit located at 113 Milton Avenue in Chapel Hill and hereafter referred to as the "Property", "Project" or the "project dwelling unit", depending on the context; and WHEREAS, OCHLT intends to acquire and lease the project dwelling unit and thereafter demolish the dwelling unit and replace it with another unit for sale to a qualified buyer, as described herein, to families earning up to 80% of HUD azea median income as described in the OCHLT Bond Program Application dated February 28, 2008 which Application is incorporated by reference into this Agreement. The February 28, 2008 Bond Program Application is on file in the office of the Orange County Department of Housing and Community Development. • WHEREAS, as particularly described herein, the Property will be held by OCHLT, ensuring affordability of the project dwelling unit for at least 99 yeazs; and 11 • WHEREAS, OCHLT has signed .this Declazation agreeing to the terms of this Declaration, its obligations pursuant to this Declaration and agreeing to the terms of the Development Agreement between the County and OCHLT of even date; and NOW, THEREFORE, in consideration of the mutual covenants, promises, and representations contained herein, it is agreed between the parties hereto as follows: SECTION 1 REPRESENTATIONS, COVENANTS AND WARRAN'T'IES OF OWNER OCHLT hereby represents, covenants and warrants as follows: a_ Subject to the requirements of the GR.AN"T AGREEMENT, an unsigned copy of which is Exhibit B hereto, and this Declazation, OCHLT may sell, transfer, or exchange the Property to a non-profit fiend, foundation, or corporation of like purpose which is organized and operated exclusively for charitable and educational purposes and which has established its tax exempt status under Section 501(c)(3) of the Internal Revenue Code, or to the County, but Owner shall notify in writing and obtain the agreement of any buyer or successor or other person acquiring the Properly or any interest therein, that such acquisition is subject to the requirements of this Declazation and to the requirements of the GRANT AGREEMENT and the Orange County Affordable Housing Bond Program. OCHLT agrees that County may void any sale, transfer, or exchange of the Properly or any portion of the Property if the buyer or successor or other person • fails to assume in writing the requirements of this Declaration and the requirements of the GRANT AGREEMENT. b. Contemporaneously with the execution, delivery and recording of this Declaration, OCHLT will acquire good and marketable title to the Properly, free and clear of any lien or encumbrance (except encumbrances created pursuant to this Declaration or other encumbrances permitted by Orange County). c. OCHLT warrants that it will not accept title to the Property subject to and will not execute any other declaration with provisions contradictory to, or in opposition to, the provisions hereof, and that in any event, the requirements of this Declaration are pazamount and controlling as to the rights and obligations herein set forth and supersede any other requirements in conflict herewith. SECTION 2 TERM OF DECLARATION a. This Declaration (and the terms of affordability specified herein) applies to the Property immediately upon the recordation of this Declaration. OCHLT and all subsequent. owners of the Property shall comply with all covenants herein. This Declaration shall terminate ninety-nine yeazs after the Project completion date as specified in the GRANT AGREEMENT. 12 • SECTION 3 RECORDING AND FILING; COVENANTS TO RUN WITH THE LAND a. OCHLT shall cause this declaration and all amendments hereto to be recorded and filed in the Office of the Register of Deeds of Orange County upon its execution. OCHI,T shall pay all fees and chazges incurred in connection therewith. b. OCHLT intends, declazes and covenants, on behalf of itself and all future owners of the Property during the term of this Declaration, that this Declaration and the covenants and restrictions set forth in this Declaration regulating and restricting the use, occupancy and transfer of the Property (1) shall be and aze covenants n~nn;ng with the land, encumbering the Property for the term of this Declazation, binding upon all present and future owners of the Property; (2) are not personal covenants of Declarant; and (3) shall bind all present and future owners (and the benefits shall inure to the County and any prospective owner of the Property) and its respective successors and assigns during the term of this Declazation. For the term of this Declazation, each and every contract, lease, deed or other instrument hereafter executed conveying the Properly or portion thereof shall expressly provide that such conveyance is subject to this Declaration, provided, however, the covenants contained herein shall survive and be effective regardless of whether such contract, lease, deed, or other instrument hereafter executed conveying the Property or portion thereof provides that such conveyance is subject to this Declaration. It is further the responsibility of OCHLT to rerecord this Declaration periodically and no less often than one day • less than every 30 yeazs from the date hereof for the purpose of renewing the rights of first refusal in the Properly or portion thereof including any leasehold interest in the Properly or portion thereof. The County retains the right to, periodically and every 30 yeazs after the first recording of the Ground Lease created in Exhibit C hereof, register, with the Register of Deeds of Orange County, a notice of preservation of the Restrictive Covenants on the Property as provided in North Cazolina General Statute § 47B-4 or any comparable preservation law in effect at the time of the recording of the notice of preservation. It is the intent of this Section 3 of this Declazation that the 99 yeaz duration of this Declazation of Restrictive Covenants be accomplished and that any future owner of the Property, OCHLT and Orange County will do what is necessary. to ensure that the same is not extinguished by N.C. Gen. Stat. § 41-29 or any comparable law purporting to extinguish, by the passage of time, preemptive rights in the Properly and by the Real Property Marketable Title Act or any compazable law purporting to extinguish, by the passage of time, non possessory interests in real properly. Any future owner of the Property, OCHLT and Orange County will to do what each must do to accomplish the ,99 year duration of this Declazation of Restrictive Covenants. SECTION 4 ENFORCEMENT OF AFFORDABLE HOUSING REQUIREMENTS a. At the time of resale of the project dwelling unit, OCHLT will convey a housing unit to qualified homebuyer. Each housing unit will consist of a 99 yeaz Ground Lease (renewable for an additiona199 yeazs) to the project dwelling unit. The Ground Lease, the form of which is Exhibit C hereto, provides for the long term affordability (at least 99 yeazs) of the housing unit and • provides remedies to insure the long term affordability of the housing unit. OCHLT hereby declazes and covenants, on behalf of itself and all future owners of the Property, that, during the 13 • term of this Declaration, the County is a third party beneficiary of and successor to each and every remedy intended to insure the long term affordability of the housing unit that is provided for in the Ground Lease and may, in the event of the failure or default of the Lessor in the Ground Lease to insure the long term affordability of the housing unit as provided for in the Ground Lease, exercise all rights and remedies available to the Lessor in the Ground Lease for that purpose, b. OCHLT covenants that it will not knowingly take or permit any action that would result in a violation of the affordability requirements of the GRANT AGREEMENT. Orange County, together with any future owner of the Properly may execute and record any amendment or modification of this Declazation necessary to insure the successful completion of the Project and the long term affordability (at least 99 years) of the housing unit on the Property and such amendment or modification shall, to the extent permitted by law, either relate back to the date of recording of this Declaration or not as necessary to carry out the intent of this Declazation, and be binding on third parties granted rights under this Declazation. OCHLT expressly covenants and agrees to rerecord this Declaration periodically and no less often than one day less than every 30 years from the date hereof for the purpose of renewing the Lessor's option to purchase and right of first refusal, that aze contained in the Exhibit. C Ground Lease, in the Property or portion thereof including any leasehold interest in the Property or portion thereof. c. OCHLT acknowledges that the primazy purpose ,for requiring compliance by OCHLT • with restrictions provided in this Declaration is to assure compliance with the long term affordability requirements of the ORANGE COUNTY HOUSING BOND PROGRAM, AND BY REASON THEREOF, OCHLT, IN CONSIDERATION FOR RECEIVING ORANGE COUNTY HOUSING BOND PROGRAM FUNDS FOR THE PROPERTY, HEREBY AGREES AND .CONSENTS THAT THE COUNTY SHALL BE ENTITLED, FOR ANY BREACH OF THE PROVISIONS HEREIN, AND IN ADDITION TO ALL OTHER REMEDIES PROVIDED BY LAW OR IN EQUITY, TO ENFORCE BY SPECIFIC PERFORMANCE OCHLT' S OBLIGATIONS UNDER THIS DECLARATION IN A STATE COURT OF COMPETENT JURISDICTION, WITH VENUE IN ORANGE COUNTY. OCHI,T hereby fiuther specifically acknowledges that the beneficiaries of OCHLT's obligations hereunder cannot be adequately compensated by monetary damages in the event of any default hereunder. If legal costs aze incurred by the County, such legal costs, including attorney fees and court costs (including costs of appeal), are the responsibility of, and may be recovered from the OCHLT. SECTION 5 NIISCELLANEOUS a. Severability. The invalidity of any clause, part, or provision of this Declaration shall not affect the validity of the remaining portions thereof. b. Notices. Any Notice shall be in writing and shall be given by depositing the same in • the United States mail, post-paid and registered or certified, and addressed to the parry to be notified, with return-receipt requested, or by delivering the same in person to an officer or 14 • principal of such party. Notice deposited in the mail in the manner herein above described shall be effective upon mailing. For purposes of Notice, the addresses of the parties shall, unless changed as hereinafter provided, be as follows: i. To the County: Orange County c% Housing and Community Development Department P.O. Box 8181 Hillsborough, NC 27278 ATTN: Director ii. To Declarant: To OCHLT: Orange Community Housing and Land Trust P.O. Box 307 Cazrboro, NC 27510 ATTN: Executive Director c. Governing Law. This Declazation shall be governed by the laws of the State of North Cazolina and, where applicable, the laws of the United States of America. IN WITNESS WHEREOF, OCHLT has caused this Declazation to be signed by its duly authorized representative, on the day and year first above written. SIGNATURES APPEAR ON FOLLOWING PAGE ~ ~ • • Orange Community Housing and Land Trust, Inc. sy: President NORTH CAROLINA ORANGE COUNTY I, , Notazy Public in and for the above named County and State, do hereby certify that on this day personally appeared before me with whom I am personally acquainted, who, being by me duly sworn, says that he is President of Orange Community Housing and Land Trust, Inc., a North Cazolina corporation, and that by authority duly given and as the act of the corporation, the foregoing instrument was signed by him on behalf of the corporation. Witness my hand and notarial seal, this the day of , 2008. Notary Public My commission expires: EXIT A Property Description Beginning at an existing iron pipe in the western right-of--way of Milton Avenue, said iron pipe being the northeastern corner of Tax Pazce17.45.A.4 as recorded in Deed Book 674, Page 316, Orange County Registry;. thence with said right-of--way, S 32 degrees 28' 36" E 79.17' to an existing iron pipe; then S 59 degrees 28' 16" W 92.47' to a point; thence N 31 degrees 56' 07" W 76.36' to a point; thence N 57 degrees 43' S3" E 91.70' to a point and place of beginning all as shown on a plat and survey entitled "Recombination Survey Property of Capkov Ventures, Inc." prepazed by Riley Surveying and recorded in Plat Book 88, Page 9, Orange County Registry, to which reference is made for a more particulaz description of same. TAX MAP 7.45.A.1 C PIN 9799-15-7927