Loading...
HomeMy WebLinkAbout2021-050-E AMS-Rice's Glass Company Sportsplex ADA door repair DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 [Departmental Use Only] TITLE Splex ADA Doors FY 2020-2021 NORTH CAROLINA CONSTRUCTION AGREEMENT UNDER$250,000.00 ORANGE COUNTY THIS CONSTRUCTION AGREEMENT (hereinafter called "Agreement"), made as of the 28th day of December, 2020, by and between Rice's Glass Company, (hereinafter called the "Contractor"), and Orange County, a political subdivision of the State of North Carolina, (hereinafter called the "County," "Orange County," or"Owner"). WITNESSETH: That the Contractor and the Owner, for the consideration herein named, agree as follows: 1. CONTRACT DOCUMENTS; PRIORITY The Contract Documents consist of this Agreement, the Request for Proposals, Proposal, Construction Drawings, and Written Specifications. The Contract Documents form the Contract. In the event of any inconsistency between or among the Contract Documents the Contract Documents shall be interpreted in the following order of priority: a. This Agreement. b. Designer Approved Bulletins and Field Orders. c. Request for Proposals and addenda thereto. d. Proposal dated October 26, 2020. 2. SCOPE OF WORK The Contractor shall furnish and deliver all of the materials, and perform all of the work required by this Agreement within the time period stipulated in a written Notice-to-Proceed to be executed by the Contractor and Owner and in accordance with the following enumerated documents, which are made a part hereof as if fully contained herein: a. Construction Drawings prepared by N/A (Sheet NONE dated NONE) b. Written specifications prepared by the project engineer. c. Rice's Glass Company proposal dated October 26, 2020 which fully describes the work to be performed. Such work will hereafter be called the "Work". d. Related documents listed under Section 1 above. 3. TERM AND SCHEDULING Revised 07/20 1 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 a. The Contractor agrees to commence work pursuant to the written Notice to Proceed. b. The Contractor agrees to complete substantially all Work by March 28, 2021. c. Time is of the essence with respect to all dates specified in the Contract Documents as Completion Dates. d. The Contractor shall perform the Work in the time, manner, and form required by the Contract Documents and as stipulated in a written Notice-to-Proceed to be executed by the Contractor and Owner. e. It is expressly understood that the Owner will employ other contractors to perform work as a part of the Project whose work will be performed simultaneously and sequentially with the performance of the Work by the Contractor. It shall be necessary for the Contractor to coordinate its activities with such other contractors, particularly with respect to access to work areas, storage of materials and other common facilities. f. Should Contractor fail to meet critical path progress of the Work, Owner may require, at no additional cost to the Owner, the Contractor to expedite and accelerate its efforts, including providing additional resources and working overtime, as necessary, to perform the Work in accordance with the approved project schedule. Should Contractor's failure to meet critical path progress of the Work be the result of factors outside of Contractor's control which nevertheless requires Contractor to expedite and accelerate its efforts, including the provision of additional resources or overtime, then Contractor shall be entitled to an equitable and corresponding adjustment to the Contract Sum to cover those additional costs. 4. STANDARD OF CARE a. The Contractor shall exercise reasonable care and diligence in performing the Work in accordance with the highest generally accepted standards of this type of Contractor practice throughout the United States and in accordance with applicable federal, state and local laws and regulations applicable to the performance of these services. Contractor is solely responsible for the professional quality, accuracy and timely completion and submission of all work. b. The Contractor shall not load or permit any part of the Work to be loaded with a weight that will endanger its safety, intended performance or configuration. c. Contractor shall be responsible for all errors or omissions caused by its employees, agents, contractors, or assigns in the performance of the Agreement. Contractor shall correct any and all errors, omissions, discrepancies, ambiguities, mistakes or conflicts at no additional cost to the Owner. d. Contractor is an independent contractor of Owner. Any and all employees of the Contractor engaged by the Contractor in the performance of any work or services required of the Contractor under this Agreement, shall be considered employees or agents of the Contractor only and not of the Owner, and any and all claims that may or might arise under any workers compensation or other law or contract on behalf of said employees while so Revised 07/20 2 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 engaged shall be the sole obligation and responsibility of the Contractor. e. If activities related to the performance of this Agreement require specific licenses, certifications, or related credentials Contractor represents that it or its employees, agents and subcontractors engaged in such activities possess such licenses, certifications, or credentials and that such licenses certifications, or credentials are current, active, and not in a state of suspension or revocation. f. The Contractor is responsible for all physical damage to owned or rented machinery, tools, equipment, forms, and other items owned, rented or used by the Contractor and Subcontractor(s) in the performance of the Work including all of Owner's property in Contractor's care, custody, or control, and all such property while it is in transit. g. The Contractor is solely responsible for obtaining all permits necessary to complete the Work in compliance with all local, state, and federal laws. 5. PAYMENT & TAXES a. The Owner hereby agrees to pay to the Contractor for the faithful performance of this Agreement, and the Contractor hereby agrees to perform all of the Work for a sum not-to- exceed Fourty-Two Thousand Five Hundred Fifty Dollars ($42,550.00). Not later than the fifth (5th) day of each calendar month the Contractor shall submit to the Owner's Representative, generally the architect if an architect is retained on the Work, a Request for Payment for work done during the previous calendar month. i. The Request for Payment shall be in form of a standardized invoice or AIA Document G702-703 appropriately addressed to Owner's Representative at Po Box 8181, Hillsborough, NC 27278 and shall show substantially the value of work done during the previous calendar month. ii. The amount due for payment shall be ninety-five percent (95%) of the value of work completed since the last Request for Payment and this amount shall be paid by the Owner on or before the last business day of the month. Owner shall retain five percent(5%). 1. Upon Owner's Representative's certification that ninety percent (90%) of the Work has been satisfactorily completed retainage may be discontinued. Retainage may be discontinued, at Owner's Discretion, so long as work continues to be completed satisfactorily and on schedule. iii. Final payment shall not be due to the Contractor until thirty (30) days after one hundred percent (100%) of the Work, including punch list work, has been satisfactorily (as determined by the County) completed and an appropriate affidavit as required in Section 7(c)below has been received by Owner. b. Should Owner reasonably determine that Contractor has failed to perform the Work related to a Request for Payment, Owner, at its discretion may provide the Contractor ten (10) days to cure the breach. Owner may withhold the accompanying payment without penalty until such time as Contractor cures the breach. i. Should Contractor or its representatives fail to cure the breach within ten (10) days, or fail to reasonably agree to such modified schedule, Owner may immediately terminate this Agreement in writing, without penalty or incurring further obligation to Contractor. In such case, Contractor shall be entitled to payment for all Revised 07/20 3 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 satisfactory work performed through the date of termination, as well as for all materials ordered but not yet incorporated into the Work. ii. This section shall not be interpreted to limit the definition of breach to the failure to perform the Work related to a Request for Payment. c. The Contractor has included in the Contract Price and shall pay all taxes assessed by any authority on the Work or the labor and materials used therein. It shall be the Contractor's responsibility to furnish the Owner documentary evidence showing the materials used and sales and use tax paid by the Contractor and each of its subcontractors. 6. INSURANCE AND BONDS a. Minimum requirements — Contractor shall obtain, at its sole expense, Commercial General Liability Insurance, Automobile Insurance, Workers' Compensation Insurance, and any additional insurance as may be required by Owner's Risk Manager as such insurance requirements are described in the Orange County Risk Transfer Policy and Orange County Minimum Insurance Coverage Requirements (each document is incorporated herein by reference and may be viewed at http://www.oran_eg countync. ov�/departments/purchasing division/contracts.php). If Owner's Risk Manager determines additional insurance coverage is required such additional insurance shall be designated here N/A (if no additional insurance required mark N/A as being not applicable). Contractor shall not commence construction work until such insurance is in effect and certification thereof has been received by the Owner's Risk Manager. b. Performance Bonds — Contractor shall furnish bonds covering the faithful performance of the Contract and payment of all obligations arising under any of the Contract Documents or related in any way to the Work. Contractor shall immediately furnish a copy of such bonds to any requesting person who appears to be a potential beneficiary of bonds covering payment obligations arising under any of the Contract Documents. This subsection 6(b) applies only to Contracts of fifty thousand dollars ($50,000.00) or more where the total cost for the project is three hundred thousand dollars ($300,000.00) or more. 7. INDEMNITY a. To the extent authorized by North Carolina law the Contractor shall indemnify, without limitation, and hold harmless to the maximum extent permitted by law the Owner and its agents and employees from and against any and all claims, damages, losses and expenses, including attorney's fees, arising out of or resulting from the performance or nonperformance of the Work, provided that any such claim, damages, loss or expense (A) is attributable to bodily injury, sickness, disease or death or injury to, or destruction of, property, including the loss of use resulting therefrom; and (B) is caused in whole or in part by any negligent or wrongful act or omission of the Contractor, any Subcontractor, or supplier of the Contractor, anyone directly or indirectly employed by any of them or anyone for whose acts any of them may be liable. The indemnification obligation under this paragraph shall not be limited in any way by any limitation of the amount or type of damages, compensation or benefits payable by or for the Contractor or any subcontractor under workers' compensation acts, disability benefits acts or other employee benefit acts. It is the intent of this section that the Contractor shall indemnify the County to the maximum extent allowed by law. Revised 07/20 4 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 b. The Contractor shall indemnify and hold harmless Owner from any lien of whatever type through the purchase of appropriate bonds and insurance as designated in Section 6 above. In the event any such lien is filed against Owner's property Contractor shall, through such bonds and insurance or at Contractors expense, defend Owner against all such claims of lien. c. Upon completion of the Work the Contractor shall execute an affidavit stating there are no unpaid debts for any work that has been done or materials that have been furnished to the project prior to and as of the date of substantial completion and further stating that Contractor shall indemnify, save and protect Owner and Owner's lender, if any, harmless from and against any and all claims, liabilities, losses, damages, causes of action, and expenses (including court costs and reasonable attorney's fees related thereto) arising out of, in connection with, or resulting from any such debts and liens. Such indemnification shall be in a form and substance acceptable to Owner. d. By executing this Agreement Contractor agrees to abide by and be bound by the indemnification provisions herein and of Section 7(c) specifically. 8. DISPUTE RESOLUTION AND GOVERNING LAW a. Any dispute with respect to any provision of, or the performance or non-performance of, this Agreement shall be subject to the Dispute Resolution Rules and Procedures for Orange County Design, Building Construction, Renovation, and Repair Projects. The policy is incorporated herein by reference and may be viewed at hqp://www.oranizecounL)Lnc.gov/departments/purchasing division/contracts.php). b. The laws of the State of North Carolina shall apply to the interpretation and enforcement of this Agreement. Any and all suits or actions to enforce, interpret or seek damages with respect to any provision of, or the performance or nonperformance of, this Agreement or the Contract shall be brought in the General Court of Justice of North Carolina sitting in Orange County, North Carolina and it is agreed by the parties that no other court shall have jurisdiction or venue with respect to such suits or actions. c. Notice of any claim by Owner or Contractor must be initiated by written notice to the other Party within thirty (30) days of the occurrence of the event giving rise to the claim or within thirty (30) days of the discovery of the event or condition giving rise to the claim, whichever is later. i. Should any claim be made, regardless of whether such claim is made by Owner or Contractor, Contractor shall continue to faithfully and diligently perform the Work in such a manner as to meet all scheduled timelines. Any failure to faithfully and diligently perform the Work may be deemed, by the Owner, a breach of the Contract. ii. If a claim is made such claim shall be made to the initial decision maker, if applicable, who may request more supporting data, reject the claim in whole or in part, approve the claim in whole or in part or advise the parties the claim is unable to be resolved. iii. If a claim is made by the Owner the Owner may, but is not obligated to, notify the surety. Revised 07/20 5 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 9. NON—APPROPRIATION a. Contractor acknowledges that Owner is a governmental entity, and the validity of this Agreement is based upon the availability of public funding under the authority of its statutory mandate. b. In the event that public funds are unavailable and not appropriated for the performance of Owner's obligations under this Agreement, then this Agreement shall automatically expire without penalty to Owner immediately upon written notice to Contractor of the unavailability and non-appropriation of public funds. It is expressly agreed that Owner shall not activate this non-appropriation provision for its convenience or to circumvent the requirements of this Agreement, but only as an emergency fiscal measure during a substantial fiscal crisis. c. In the event of a change in the Owner's statutory authority, mandate or mandated functions, by state or federal legislative or regulatory action, which adversely affects Owner's authority to continue its obligations under this Agreement, then this Agreement shall automatically terminate without penalty to Owner upon written notice to Contractor of such limitation or change in Owner's legal authority. 10. NOTICES Any notice required by this Agreement shall be in writing and delivered by certified or registered mail, return receipt requested to the following: Owner: Contractor: Orange County Rice's Glass Company Attn: AMS Attn: Wesley Quick P.O. Box 8181 107 Lloyd St. Hillsborough,NC 27278 Carrboro,NC 27510 11. MISCELLANEOUS a. Duties and Obligations imposed by the Contract Documents shall be in addition to any Duties and Obligations imposed by state, federal or local law, rules, regulations and ordinances. b. No act or failure to act by the Owner or Contractor shall constitute a waiver of any right or duty granted them under the Contract Documents, nor shall any act or failure to act constitute any approval except as specifically agreed in writing. c. The Work shall be tested and inspected as required by the Contract Documents and as required by law. Unless prohibited by law the costs of all such tests and inspections related to state and federal codes such as ADA, Administrative, Electrical, Plumbing, Mechanical and Building Codes shall be borne by the Contractor. The costs for material and structural testing shall be conducted by an independent third party at the expense of the Owner. Delays related to any of the aforementioned tests and inspections shall not be grounds for delaying the completion of the work. If any such tests and inspections reveal deficiencies in the Work such that the Work does not comply with terms or requirements of the Contract Documents and the requirements of any code or law the Contractor is solely responsible for the cost of bringing such deficiencies into compliance with the terms of the Contract Documents and any code or law. Revised 07/20 6 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 d. Should the Architect, if an architect is retained for the project involving the Work, or Owner reject any portion of the Work for failing to comply with the Contract Documents Contractor shall immediately, at Contractor's expense, correct the Work. Any such rejection may be made before or after substantial completion. If applicable, any additional expense borne by the Architect under this section shall be paid at Contractor's expense. e. The Contractor shall not assign any portion of this Agreement nor subcontract the Work in its entirety without the prior written consent of the Owner. f. By executing this Agreement Contractor affirms that Contractor and any subcontractors of Contractor are and shall remain in compliance with Article 2 of Chapter 64 of the North Carolina General Statutes. g. By executing this Agreement Contractor certifies that Contractor has not been identified, and has not utilized the services of any agent or subcontractor identified, on the list created by the State Treasurer pursuant to G.S. 147-86.58. h. By executing this Agreement Contractor certifies that Contractor has not been identified, and has not utilized the services of any agent or subcontractor identified, on the list created by the State Treasurer pursuant to G.S. 147-86.81. i. The County has designated(Angel Barnes)to act as the County's representative with respect to the Work and shall have the authority to render decisions within guidelines established by the County Manager or the County Board of Commissioners and shall be available during working hours as often as may be reasonably required to render decisions and to furnish information. j. Contractor shall at all times remain in compliance with all applicable local, state, and federal laws, rules, and regulations including but not limited to all state and federal non- discrimination laws, policies, rules, and regulations and the Orange County Non- Discrimination Policy and Orange County Living Wage Policy(each policy is incorporated herein by reference and may be viewed at http://www.oran eg cogptync• ov�/departments/purchasing division/contracts.php). Any violation of the Orange County Non-Discrimination Policy is a breach of this Agreement and County may immediately terminate this Agreement without further obligation on the part of the County. This paragraph is not intended to limit and does not limit the definition of breach to discrimination. k. This Agreement together with any amendments or modifications may be executed electronically. All electronic signatures affixed hereto evidence the consent of the Parties to utilize electronic signatures and intent of the Parties to comply with Article I I A and Article 40 of North Carolina General Statute Chapter 66. 1. Upon request of the Owner, the Contractor shall submit to County all relevant documentation, including but not limited to,job cost records, to support its claims for final compensation and if such request is made final compensation shall not be due until all relevant documentation is received, reviewed, and approved by Owner. Revised 07/20 7 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 12. CONSEQUENTIAL AND LIQUIDATED DAMAGES a. Owner and Contractor mutually waive any claim against each other for consequential damages. Consequential Damages include: i. Damages incurred by Owner for loss of use, income, financing, or business. ii. Damages incurred by Contractor for office expenses, including personnel, loss of financing, profit, income, business, damage to reputation, or any other non-direct damages. b. Liquidated damages shall be in accord with the Contract Documents. If the Contract Documents do not otherwise address liquidated damages, such damages shall be in the amount of one hundred dollars ($100.00)per day. 13. TERMINATION OR SUSPENSION a. The Owner may, without cause, order the Contractor to terminate, suspend, delay or interrupt the Work in whole or in part for such period of time as the Owner may determine. i. If Owner issues a written order to delay, suspend, or interrupt the Work, and such order is not due to or as a result of any fault on the part of the Contractor or any subcontractor, the Contractor may recover a per diem amount of five hundred dollars ($500.00) per day with a not-to-exceed limit of ten thousand dollars ($10,000.00). ii. In the event of termination by the Owner under this Agreement, the Contractor shall be entitled to receive its reasonable and documented direct costs prior to termination, including the cost of materials purchased for the Work which purchases cannot be canceled or which material cannot reasonably be used by the Contractor on other work, and the cost of closing down the work in a safe and efficient manner. iii. If Owner elects to suspend or terminate the contract pursuant to subparagraphs 13.a.i. or 13 a.ii. the sole remedy available to the Contractor are those listed in the subparagraphs and Contractor is not entitled to any right to further claims for any amount owed or disputed or for payment of damages alleged to have been sustained as a result of Owner's order to delay, suspend, or interrupt the Work. b. The Owner may, with cause, order the Contractor to suspend, delay or interrupt the Work in whole or in part for such period of time as the cause remains. i. If Owner issues a written order to delay, suspend, or interrupt the Work, and such order is due to or as a result of any fault on the part of the Contractor or any subcontractor, the Owner may reduce payment at a per diem amount of five hundred dollars ($500.00)per day. c. Contractor may terminate the Contract if, at the Owner's written direction, the Work is stopped for twenty one (21) consecutive days through no act or fault of the Contractor, their agents or employees, or a subcontractor or their agents or employees or any other person performing work pursuant to the Contract Documents. Contractor may terminate Revised 07/20 8 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 the Contract if a Court or other Public authority having jurisdiction enters a lawful order that requires all work to be stopped and such stoppage lasts for twenty one (21) consecutive days. d. Either party may terminate this Agreement upon notice to the other party that obligations pursuant to this Agreement are made impossible due to declarations of emergency by Orange County or by North Carolina due to events directly impacting Orange County. Both parties shall remain responsible for all payment and performance due up to the receipt of such notice, but shall have no further obligation or responsibility beyond that date provided the terminating party has taken all reasonable steps to complete the performance of its obligations. 14. ENTIRE AGREEMENT All of the documents listed, referenced or described in this Agreement, the written Notice-to- Proceed, together with Modifications made or issued in accordance herewith are the Contract Documents, and the work, labor, materials and completed construction required by the Contract Documents and all parts thereof is the Work. The Contract Documents constitute the entire agreement between Owner and Contractor. This Agreement may be amended only by written instrument signed by both parties. Modifications may be evidenced by facsimile signatures. If any provision of the Agreement shall be declared invalid or unenforceable, the remainder of the Agreement shall continue in full force and effect. IN WITNESS WHEREOF, the Parties hereto have executed this Agreement as of the day and date first above written wholly or in a number of counterparts each of which shall, without proof or accounting for other counterparts, be deemed an original contract. ORANGE COUNTY CONTRACTOR g sgn.a ny: g s g a nr: WAk R M KI 1/5/2021 1/4/2021 PBSrg!lEr.i5Ella.. �C�'9M4"-'.. Signature Signature County Manager Wesley Qui Ck Project Manager Printed Name and Title Revised 07/20 9 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 ORANGE COUNTY-DEPARTMENT USE ONLY Party/Vendor Name: Rice's Glass Company Party/Vendor Contact Person: Wesley Quick(wesleyAricesglasscompM.com) Contact Phone: 919.967.9214 Party/Vendor Address: 107 Lloyd St. City Carrboro State: NC Zip: 27510 Department: AMS/Sportsplex Amount: $42,550.00 Purpose: Snortsplex - Repair/Replace Doors Budget Code(s): 54540030 800000 Vendor# 104 (N/A if new vendor) Vendor is a BOCC consultant? Yes ❑ No® Contract Type: (Check one) New Renewal F Amendment ❑ Effective Date 12/28/2020 Approved by Board Yes❑No® Agenda Date: This agreement is approved as to technical form and content and I as Department Director affirmatively state work on this project has not been initiated prior to execution of the agreement: D s'g g by: Department Director's Signature V­RMA Date: 1/4/2021 =zoogwsgeieaacs_. Agreements for emergency services or repair are not subject to the above affirmation. If services related to this agreement have already begun or been completed please briefly describe the nature of the emergency condition that was addressed: N/A Risk Management This agreement is approved for sufficiency of insurance standards, specifications,and requirements: D sg aby: Office of the Risk Management Office QUsa(mu{fe rag gl, Date: 1/4/2021 gg8g 8 Financial Services This instrument has been pre-audited in the manner required by the Local Government Budget and Fiscal Control Act: P( D Sig—by: 1/5/2021 Office of the Chief Financial OfticerE_ �"" Date: ,DaEs,g.A Legal Services This agreement is approved as to legal form and sufficiency: D sg gby: Office of the County Attorney LJW hniw Date: 1/5/2021 aC5F3CDOF0H9IIF3.. Clerk to the Board Received for record retention: All Docusign contracts must be copied to the Clerk upon completion: occlerkdocs@orangecountync.gov The following signature block is for hard copies only and is not required for Docusign contracts: Office of the Clerk to the Board Date: Revised 07/20 10 DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 RI C E 'S G LAS S- C 0 M P A N Y 107 Lloyd St. Carrboro, NC 27510 Ph: 919-967-9214 Fax: 919-967-4623 10.26.2020 Quote #WQ-20-1493 Re: Orange County Sports Plex Pool Area Rice's Glass Company is pleased to quote material and labor for this project. We include work as found in scope of work below. • 1 3/4" x 4 %2" Interior Storefront Entrances. • Finish to be "Clear" Anodized. • Glazing to be 1/4" Clear Tempered. • 4 - Doors to be Medium Stile 3'-0" x 8'-0" With Transoms, 1 - Pair 6'-0" x 7'-0" Rear Pool Entry. Manufacturers Standard Hardware to include Continuous Hinges in Lieu of Butt hinges. (4) Low Energy Operators and wireless push/pads, BTB push/pull handles. No locks. • Storefront will have to be removed and reworked with appropriate snap in pocket filler. • HDW for rear entry pool door to be Heavy Duty surface mounted closers, RIM Panic exit devices with Removable Mullion. • Hockey Rink Doors to be (4) W-0 x 7'-0 with Transoms. Hardware to be heavy duty surface mounted closers, btb push pulls, no thresholds, %4" Clear Tempered Glazing. Qualifications: No panic devices are quoted at the pool vestibule entry nor the hockey rink as these doors have no locks and will remain open at all times to allow free egress. TOTAL INVESTMENT BASE BID POOL AREA:------------------$26,555.00 TOTAL INVESTMENT HOCKEY RINK:-----------------------------$15,995.00 NOTE: This proposal is only valid for 30 days. Exclusions: Hardware, cleaning and protection, composite crew cleaning, bonds, permits, window film, all other interior work, mirrors, mock up, extended warranties, any break metal trim not specifically called out in the drawings, automatic sliders and their glazing, 120V to electrified hardware, low voltage wiring, alarms, electric strikes, auto operators, hollow metal doors and frames, wood blocking, custom colors, sunshade awnings, engineering, demolition, wood blocking and or trim. DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 RI C E 'S G LAS S. COMPANY Best, Wesley Quick - PM/Estimator Rice's Glass Company Commercial Products Division 919-967-9214 Office 919-448-5575 Cell Signature Date DocuSign Envelope ID:5F221640-OC6A-45CC-B6E3-598D286D5D34 DATE(MM/DD/YYYY) A�" CERTIFICATE OF LIABILITY INSURANCE 11/19/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND,EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Diane Nadeau NAME: Business Insurers of Carolinas aCC Ext: (919)968-4611 AIX No): (919)968-8991 501 Eastowne Drive,Suite 250 E-MAIL dnadeau@business-insurers.com ADDRESS: PO Box 2536 INSURER(S)AFFORDING COVERAGE NAIC# Chapel Hill NC 27515 INSURERA: Union Insurance Company 25844 INSURED INSURER B: Wesco Insurance Company 25011 Rice's Glass Company,Inc. INSURER C: PO Box 40 INSURER D: INSURER E: Carrboro NC 27510 INSURER F: COVERAGES CERTIFICATE NUMBER: CL2092129638 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCEADDLSUBR POLICY EFF POLICY EXP LTR INSD WVD POLICY NUMBER MM/DD/YYYY MM/DD/YYYY LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR PRIM SES Ea oNcE ence $ 500,000 MED EXP(Any one person) $ 10,000 A CPA4349078 09/23/2020 09/23/2021 PERSONAL&ADV INJURY $ 1,000,000 MOTHER LAGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY PRO ❑ LOC PRODUCTS-COMP/OP AGG $ 2,000,000 JECT: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 Ea accident X ANYAUTO BODILY INJURY(Per person) $ A OWNED SCHEDULED CPA4349078 09/23/2020 09/23/2021 BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY Per accident Uninsured motorist $ 1,000,000 UMBRELLALIAB 5,000,000 OCCUR EACH OCCURRENCE $ A EXCESS LAB HCLAIMS-MADE CPA4349078 09/23/2020 09/23/2021 AGGREGATE $ 5,000,000 DED I RETENTION $ $ WORKERS COMPENSATION X I STATUTE EREIR H AND EMPLOYERS'LIABILITY Y/N 1,000,000 ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ B OFFICER/MEMBER EXCLUDED? NIA WWC3493767 09/23/2020 09/23/2021 (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under 1,000,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ Leased/Rented Equipment Limit $100,000 A CPA4349078 09/23/2020 09/23/2021 Deductible $1,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached if more space is required) CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,NOTICE WILL BE DELIVERED IN Orange County ACCORDANCE WITH THE POLICY PROVISIONS. PO Box 8181 AUTHORIZED REPRESENTATIVE Hillsborough NC 27278 n (� ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD