Loading...
HomeMy WebLinkAboutAgenda - 03-06-2001-8hORANGE COUNTY BOARD OF COMMISSIONERS ACTION AGENDA ITEM ABSTRACT Meeting Date: March 6, 2001 Action Age Item No. ~~ SUBJECT: HOME Program -- Second MortgacLe Assistance DEPARTMENT: Housing/Comm. Development PUBLIC HEARING: (Y/N) No ATTACHMENT(S): Development Agreement INFORMATION CONTACT: Tara L. Fikes, ext 2490 TELEPHONE NUMBERS: Hillsborough 732-8181 Chapel Hill 9fi8-4501 Durham fi88-7331 Mebane 336-227-2031 PURPOSE: - - To authorize the execution of a Development Agreement with Habitat for Humanity of Orange County, Inc. on behalf of the Orange County HOME Consortium to provide second mortgage assistance for five (5) low-income families and authorize the Manager to execute the document upon the approval of the County Attorney. BACKGROUND The Orange County HOME Consortium, in May 2000 approved the FY 2000 HOME Program that included an. allocation of $62,500 to provide second mortgage assistance for five (5) low- income families purchasing homes constructed by the non-profit agency, Habitat for Humanity of Orange County, Incorporated. The agency intends to complete construction of four (4) homes in the Chestnut Oaks in the Bingham Township in the next few months and one (1) in the Efland Estates subdivision in Efland. First-time homebuyers with incomes at or below 50% of the area median income will purchase these homes. HOME funds will be used to provide second mortgage assistance in the amount of $12,500 per family in order to lower the amount of the first mortgage held by the family. As the lead entity for the Orange County HOME Consortium, the County must enter into a Development Agreement with Habitat for Humanity for the expenditure of HOME funds for this property acquisition. FINANCIAL IMPACT: This action will represent an expenditure of $62,500 from the 2000 HOME Program allocation. A Declaration of Deed Restriction, Promissory Note and Deed of Trust will secure each second mortgage in the amount of $12,500 on the property. RECOMMENDATION(S): The Manager recommends that the Board authorize the execution of a Development Agreement with Habitat for Humanity of Orange County, Inc. on behalf of the Orange County HOME Consortium to provide second mortgage assistance for five (5) low- income families and authorize the Manager to execute the document upon the approval of the County Attorney. 2q NORTH CAROLINA ORANGE COUNTY DEVELOPMENT AGREEMENT This is an AGREEMENT between ORANGE COUNTY, a general local governmental unit of the State of North Carolina, (hereinafter referred to as the "County") and HABITAT FOR HUMANITY OF ORANGE COUNTY, NC, INC. , a North Carolina non-profit housing organization (hereinafter referred to as "Habitat"). The effective date of this agreement is March 6, 2000. WITNESSTH WHEREAS, the Orange County HOME Consortium has designated $62,500 in FY 2000 HOME funds for the purpose of providing second mortgage assistance for five (5) low-income families purchasing homes built by Habitat for Humanity of Orange County, NC, Inc.. WHEREAS, the County is the lead entity of the Orange County HOME Consortium, so designated in an agreement dated July 1, 1997 and as such is the lead entity in a representative capacity for all members of the Orange HOME Consortium for the purposes of carrying out the HOME Program in accordance wit the Title II of the Cranston-Gonzalez National Affordable Housing Act (Pub. L. 101-625), (42 U.S.C. 3535(d) et. seq.) (hereinafter referred to as the "Act"), and as further defined in the Federal Program Requirements provided by the U.S. Department of Housing and Urban Development; and WHEREAS, Habitat intends to construct five single family dwelling units on the property available to first-time homebuyers earning up to 50°Io of HUD area median income as described in their HOME Program Proposal dated March 20, 2000 which is Exhibit B to this Agreement, and hereafter referred to as "'The Project". WHEREAS, afirst-time homebuyer for the purposes of this program is defined as any household earning up to 50% of HUD area median income that has not owned a home within the past three (3) years including households living in manufactured housing not permanently affixed to a foundation, or owner-occupants of homes not feasible for rehabilitation. NOW, THEREFORE, in consideration of the mutual covenants, promises, and representations contained herein, it is agreed between the parties hereto as follows: 1. Project Activities 1.1. Habitat shall sell the newly constructed dwelling units to qualified buyers whose income is up to 50% of the area median household income by family size, as determined by the U.S. Department of Housing and Urban Development at the time of the sale. 3 1.2 The HOME funding provided by the County will be provided as a deferred second mortgage to the individual families at the time of sale. The HOME Program investment will be secured by a forty (40) yeaz Deed of Trust and Promissory Nate, forgivable at the end of 40 years. This Deed of Trust and Promissory Note shall constitute a lien on the Property, second only to the Declazation of Restrictive Covenants described in paragraph 4 of this Agreement, with the County as ,the secured party/beneficiary. The County agrees to subordinate its Deed of Trust lien to a lien securing private permanent financing acquired by the homebuyer. 1.3 The period of affordability will be 99 yeazs and will be secured by a Declaration of Restrictive Covenants that will incorporate a right of first refusal that may be exercised by Habitat and/or Orange County. 1.4 Habitat is responsible for soliciting buyers for the five, new dwelling units. Habitat and/or its buyers shall be responsible for securing permanent mortgage financing for the homes. l.5 Habitat is responsible far verifying the income of the homebuyers, explaining the second mortgage program to potential homebuyers and certifying by written documentation signed by the homebuyer that the program requirements have been fully explained. Habitat shall maintain purchaser files as part of its Books and Records as required and for the period of time required by Section 6.c. of this Agreement. 2. Time for Commencement and Completion. In addition, Habitat agrees to furnish to the County a copy of its annual audit, performed by a certified public accountant within 90 days of the end of the fiscal year of expenditure of the HOME Program Funding. The Project completion date is the closing date of the purchase by a qualified buyer of the last of the five units to be constructed. In the event that Habitat is unable to proceed with any aspect of the Project in a timely manner, and County and Habitat determine that reasonable extension(s) for completion will not remedy the situation, then the Termination of Agreement provisions of this Agreement (Section 6.a.) shall pertain. Habitat may, at its option, submit a written request for a delay of completion for County approval. The County may, at its option, approve any delay in the completion date or declaze Habitat in default. Habitat shall monitor the constructed units for affordability for the period of affordability -- ninety-nine (9y) yeazs. Final contract completion date shall be the' latest end date of all assisted unit affordability periods. 3. Affordability Requirement. Each unit must remain affordable for a period of ninety- nine yeazs. Habitat retains full responsibility for compliance with the affordability requirement far assisted units, unless affordability restrictions are terminated due to the sale of the Property to anon-qualified buyer in which event the Resale Provisions of 4 Section 5 of this Agreement pertain. Habitat shall assure compliance with affordability of assisted units by having recording, at the time it sells each of the twenty-five dwelling units, a "Declaration of Restrictive Covenants" (EXHIBIT C) on the Property. This Declazation shall constitute and remain a first lien on the Property during the period of affordability. It is further the responsibility of Habitat to rerecord the Declazation of Restrictive Covenants no later than one day before the expiration of 30 years of the date of its sale of each of the five dwelling units in the event the homeowner purchasing the property from Habitat is still the owner of the dwelling unit at the time of the rerecording. County retains the right to periodically and every 30 yeazs after the first recording of the Declaration of Restrictive Covenants on the Property to register, with the Register of Deeds of Orange County, a notice of preservation of the Restrictive Covenants on the Property as provided in North Cazolina General Statute § 47B-4 or any comparable preservation law in effect at the time of the recording of the notice of preservation. It is the intent of this Section of this Agreement that the 99 yeaz affordability requirement contained herein be accomplished and that Habitat and the County will do what is necessary to ensure that the same is not extinguished by the Real Property Mazketable Title Act or any comparable law purporting to extinguish, by the passage of time, non possessory interests in real property. Both Habitat and County agree to do what each must do to accomplish the 99-year affordability requirement. a. Resale Provisions. Habitat shall assure compliance with affordability of assisted units through the Declaaation of Restrictive Covenants. The Declaration of Restrictive Covenants shall include at least the following elements in their resale provisions for the Improvements: 4.1 If the buyer no longer uses the Property as a principal residence or is unable to continue ownership, then the buyer must sell, transfer, or otherwise dispose of their interest in the Property only to a qualified homebuyer, i.e., aloes-income household, one whose combined income does not exceed 50°Io of the area median household income by family size, as determined by the U.S. Department of Housing and Urban Development at the time of the transfer, to use as their principal residence. 4.2 However, if the property is sold during the term of affordability to anon-qualified homebuyer, the Right of First Refusal provision of the New and Existing First- Time Homebuyer Program portion of the County's Long-Term Housing Affordability Policy must be followed and the net sales proceeds (sales price less: (1) selling cost, (2) the unpaid principal amount of the original first mortgage and (3) the unpaid principal amount of the initial County contribution and .any other initial government contribution secured by a deferred payment promissory note and deed of trust) or "equity" will be divided 50/50 by the seller of the Property and the County. 5 4.3 The resale provision shall remain in effect for the full affordability period - 99 years. 5. Miscellaneous Provisions. a. Termination of Agreement. The full benefit of the Project will be realized only after the completion of the affordability periods for all properties constructed with funds provide affordable units to low-income families. It is the County's intention that the full public benefit of this project shall be completed under the auspices of Habitat for the assisted units as follows: i. In the event that Habitat is unable to proceed with any aspect of the Project in a timely manner, and County and Habitat determine that reasonable extension(s) for completion will not remedy the situation, then Habitat will retain responsibility for requirements for any dwelling units assisted and County will make no further payments to Habitat. ii. In the event that Habitat, prior to the contract completion date, is unable to continue to function due to, but, not limited to, dissolution or insolvency of the organization, its filing a petition for bankruptcy or similar proceedings, or is adjudged bankrupt or fails to comply or perform with provisions of this agreement, then Habitat shall, upon the County's request, convey to the County the properties assisted with funds. Conveyance shall be at the sole discretion of County and on a dwelling unit by dwelling unit basis. Conveyance of properties shall be on the terms set forth herein: Conveyance of properties shall occur within thirty (3U) days of County and Habitat's agreement of Habitat's inability to continue as a viable organization. Habitat shall convey the subject properties to County by general warranty deed, free and clear of all liens and encumbrances of record except those which create a beneficial interest in County (Declaration of Restrictive Covenants and Deed of Trust). b. Default, Remedies. This Agreement may be terminated by anon-defaulting party upon an event of default hereunder, after written notice thereof and thirty (30) days grace period in which the defaulting party may act to cure. As used herein, the term "an event of default" shall mean and refer to a failure or act of omission by either parry with respect to any undertaking, obligation, covenant or condition as set forth in this Agreement. With respect to any event of default, the non-defaulting party may exercise any right available to it at law or in equity with respect to such default. c. Books and Records. Habitat shall maintain records of its grant requirements under this contract for ninety-nine (99) years following the contract completion date or until the last of the housing units that are part of the Project is sold to a nonqualified buyer, whichever first occurs. i. Habitat shall ensure access to records and Financial statements, as necessary, to pravide effective monitoring and evaluation of ,project performance. Upon reasonable 6 advance notice, County or its authorized representatives may from time to time inspect, audit, and make copies of any of Habitat's records that relate to this contract. If any audit by County discloses that payments to Habitat were in excess of the amount to which Habitat was entitled under this contract, Habitat shall promptly pay to County the amount of such excess. If the excess is greater than 1% of the contract amount, Habitat shall also reimburse County its reasonable costs incurred in performing the audit. ii. Habitat shall maintain files of all buyers, regardless of length of occupancy, residing in assisted units. Documentation shall verify eligibility for federal assisted housing, at the paint of initial closing on the unit, and every subsequent buyer thereafter for the period of affordability. Information maintained shall include buyer income level, ethnic data, female head of household, and disability status and Property and Improvement purchase price. iii. Habitat shall maintain records verifying the affordability of the assisted units. d. Notices. Any Notice shall be in writing and shall be given by depositing the same in the United States mail, post-paid and registered or certified, and addressed to the party to be notified, with return-receipt requested, or by delivering the same in person to an officer or principal of such party. Notice deposited in the mail in the manner here in above described shall be effective upon mailing. For purposes of Notice, the addresses of the parties shall, unless changed as hereinafter provided, be as follows: i. To the County: Orange County c/o Housing and Community Development Department P.O. Box 8181 Hillsborough, NC 27278 ATTN: Director ii. To Habitat: Habitat for Humanity of Orange County, NC, Inc. P.O. Box 4Q7 Hillsborough, NC 27278 ATTN: Executive Director Either the County or Habitat may change the person or address to which any future Notice shall be given as herein provided. e. No Assignment. No transfer or assignment of the interest of Habitat in this Agreement shall occur without the prior written consent of the County; neither may Habitat assign this Agreement without the prior written consent of County. f. Binding Effect. This Agreement shall be binding upon and shall inure to the benefit of the parties hereto and their respective successors and assigns. 7 g. Indemnification. To the extent legally possible, Habitat shall indemnify and hold County, its officers, agents, and employees, harmless from and against any and all claims, actions, liabilities, costs, including attorney fees and other costs of defense, arising out of or in any way related to any act or failure to act by Habitat, its employees, agents, officers, and contractors in connection with this contract. In the event any such action or claim is brought against County, Habitat shall, upon County's tender, defend the same at Habitat's sole cost and expense, promptly satisfy any judgment adverse to County or to County and Habitat jointly, and reimburse County far any loss, cost, damage; or expense, including attorney fees suffered or incurred by County. h. Subcontracting. Habitat shall not subcontract work under this contract, in whole or in part, without County's prior written approval. Habitat shall require any approved subcontractor to agree, as to the portion subcontracted, to comply with all applicable federal, state, and local laws, rules, ordinances, and regulations at all times and in the performance of the work and to comply with all obligations of Habitat specified in this contract. Notwithstanding County's approval of a subcontractor, Habitat shall remain obligated for full performance of this contract and County shall incur no obligation to any subcontractor Habitat shall indemnify, defend, and hold County hazmless from all claims of its contractors. i. No Joint Venture or Agency. The County and Habitat each agree and acknowledge that nothing contained herein or otherwise, including, without limitation, any act of the County or Habitat under this Agreement, shall be deemed or construed to create any relationship of joint venture, partnership or agency between the parties. j. Effect of Waiver or Forbearance. No failure by the County to insist upon the strict performance of any term or condition of this Agreement, or to exercise any right or remedy upon the breach by Habitat of any of its obligations, agreements, or covenants hereunder, shall be a waiver of such affected term or condition or of such breach; nor shall any forbearance by the County to seek a remedy for any breach by Habitat be a waiver by the County of its rights and remedies with respect to that or any other breach. k. Governing Law. This Agreement shall be construed in accordance with and governed by the laws of the State of North Cazolina. Any litigation arising out of this Agreement shall be brought in courts sitting in North Cazolina, with venue in Orange County. 1. Severability. The provisions of this Agreement aze independent of and sepazable from each other, and no provision shall be affected or rendered invalid or unenforceable by the fact that for any reason any other provision may be invalid or unenforceable in whale or in part. If any provision of this Agreement or the application thereof to any person or circumstances shall, to any extent, be or become invalid or unenforceable, the remainder of this Agreement, or the application of such provision to persons, or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each provision of this Agreement shall be valid and be enforced to the fullest extent permitted by law. The County and Habitat agree to substitute for such provision of this Agreement or the application thereof determined to be invalid or unenforceable, such other provision as most closely approximates, in a lawful manner, such invalid, illegal or unenforceable provision. If the County and Habitat cannot agree, they shall apply to a court of competent jurisdiction to substitute such provision as the court deems reasonable and judicially valid, legal and enforceable. Such provision determined by the court shall automatically be deemed part of this Agreement ab initio. 8 m. Equal Opportunity. Habitat shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, political affiliation or belief, age, handicap, or familial status in the implementation of this Project. Further, Habitat shall provide a Statement regazding the utilization of minority and women- owned businesses in the planning and development of the Project. This statement will be Exhibit D to this agreement. n. Headings. Headings aze for convenience only and shall not be used to interpret or construe its provision. o. Gender; Singular and Plural. As used herein, the neuter gender includes the feminine and masculine. The masculine includes the feminine and neuter, and the feminine includes the masculine and neuter and each includes a corporation, partnership or other legal entity when the context so requires. The singular number includes the plural and vice versa, whenever the context so requires. p. Recording. The parties hereto agree that upon notice to the other and at its own cast and expense, a party may record this Agreement in the Office of Register of Deeds for Orange County. q. Compliance with Laws. To the extent applicable, each party hereto agrees to comply with all laws, ordinances and regulations affecting the Property from and after the date hereof. Without limiting the generality of the foregoing, Habitat shall comply with all federal, state and local laws, regulations and ordinances applicable to the expenditure of funds provided by the County, to purchase and develop the Property. r. Publicity; Signage. Habitat agrees to provide such publicity with respect to the County's participation in the development of the Property as the County shall reasonably require. any signage at the Property shall acknowledge the County's role and contribution. s. Counterparts. This Agreement may be executed in one or mare counterparts, each of which shall be deemed an original but all of which together shall constitute on and the same instrument. t. No Third Party Rights. The parties hereto covenant and agree that nothing contained in this Agreement or any act by the County or Habitat shall be deemed or construed by the parties or any third parry to create any relationship of third party beneficiary, including third party principal or agent, or to create any right, claim or cause of action against the County, Habitat or any of their respective officers, agents or employees by any third parry. u. Performance of Government Functions. Notwithstanding anything in this Agreement which may be to the contrary, nothing contained in this Agreement shall in any way stop, limit or impair the County from exercising or performing any regulatory, policing or governmental powers or functions with respect to the Property including, without limitation, inspection of the Property in the performance of such functions. 9 IN WITNESS WHEREOF, the parties hereto, intending to be legally bound, have set their hands and seals on the day and year first above written. COUNTY OF ORANGE, NORTH CAROLINA (SEAL) John M. Link, Jr., County Manager ATTEST: Beverly A. Blythe Clerk to the Board of Commissioners Approved as to form and legality Geoffrey Gledhill, County Attorney This document has been preaudited in accordance with the N.C. Local Government and Fiscal Control Act. Kenneth Chavious, Finance Director NORTH CAROLINA ORANGE COUNTY This is to certify that on this day personally came before me Beverly A. Blythe, with whom I am personally acquainted, and being by me duly sworn, says that John M. Link, 7r. is the County Manager of Orange County, NC, and that she the said Beverly A. Blythe, is the Clerk to the Board of Commissioners of the County of Orange, the body politic and corporate named within and which executed the foregoing instrument; that she knows the common seal of said County; that the seal affixed to said instrument is said common seal; that the name of Orange County was subscribed thereto by the said, County Manager of Orange County, NC and said Beverly A. Blythe subscribed their names hereto and said common seal was affixed, all by order of the Board of County Commissioners of Orange County and that said instrument is the act and deed of Orange County. Witness my hand and notarial seal, this the day of 20~.. Notary Public My commission expires: 10 Habitat for Humanity of Orange County, NC, Inc. (SEAL) President ATTEST: Secretary NORTH CAROLINA ORANGE COUNTY I, ,Notary Public in and for the above named County and .State, do hereby certify that on this day personally appeared before me with whom I am personally acquainted, who, being by me duly sworn, says at he is Secretary and that is President of Habitat far Humanity of Orange County, NC, Inc., a North Cazolina corporation, and that by authority duly given and as the act of the corporation, the foregoing instrument was signed in its name by its President, sealed with its corporate seal and attested to by its Secretary. Witness my hand and notarial seal, this the day of 20_. Notary Public My commission expires: