Loading...
HomeMy WebLinkAbout2016-572 Planning - Vaughn and Melton Consulting Engineers - Professional Engineering Services - Stream Buffer Study �lanni�� [Departmental Use Only] TITLE Stream Buffer Study FY 2016-17 NORTH CAROLINA SERVICES AGREEMENT UNDER $90,000.00 RFP ORANGE COUNTY This Services Agreement (hereinafter"Agreement"), made and entered into this 16th day of September, 2016, ("Effective Date") by and between Orange County, North Carolina a political subdivision of the State of North Carolina (hereinafter, the "County") and Vaughn and Melton Consulting Engineers, (hereinafter, the "Provider"). WITNESSETH: That the County and Provider, for the consideration herein named, do hereby agree as follows: 1. Services a. Scope of Work. i) This Services Agreement ("Agreement") is for professional services to be rendered by Provider to County with respect to (insert type of project): Stream Buffer study for Orange County as detailed in RFQ#5219 ii) By executing this Agreement, the Provider represents and agrees that Provider is qualified to perform and fully capable of performing and providing the services required or necessary under this Agreement in a fully competent, professional and timely manner. iii) Time is of the essence with respect to this Agreement. iv) The services to be performed under this Agreement consist of Basic Services, as described and designated in Section 3 hereof. Compensation to the Provider for Basic Services under this Agreement shall be as set forth herein. 2. Responsibilities of the Provider a. Services to be provided. The Provider shall provide the County with all services required in Section 3 to satisfactorily complete the Project within the time limitations set forth herein and in accordance with the highest professional standards. b. Standard of Care. i) The Provider shall exercise reasonable care and diligence in performing services under this Agreement in accordance with the highest generally accepted standards of this type of Provider practice throughout the United States and in accordance with applicable federal, state and local laws and regulations applicable to the Revised 6/16 1 performance of these services. Provider is solely responsible for the professional quality, accuracy and timely completion and/or submission of all work related to the Basic Services. ii) Provider shall be responsible for all errors or omissions of its agents, contractors, employees, and assigns in the performance of the Agreement. Provider shall correct any and all errors, omissions, discrepancies, ambiguities, mistakes, or conflicts at no additional cost to the County. iii) The Provider shall not, except as otherwise provided for in this Agreement, subcontract the performance of any work under this Agreement without prior written permission of the County. No permission for subcontracting shall create, between the County and the subcontractor, any contract or any other relationship. iv) Provider is an independent contractor of County. Any and all employees of the Provider engaged by the Provider in the performance of any work or services required of the Provider under this Agreement, shall be considered employees or agents of the Provider only and not of the County, and any and all claims that may or might arise under any workers compensation or other law or contract on behalf of said employees while so engaged shall be the sole obligation and responsibility of the Provider. v) If activities related to the performance of this Agreement require specific licenses, certifications, or related credentials Provider represents that it and/or its employees, agents and subcontractors engaged in such activities possess such licenses, certifications, or credentials and that such licenses certifications, or credentials are current, active, and not in a state of suspension or revocation. 3. Basic Services a. Basic Services. i) The Provider shall perform as Basic Services the work and services described herein and as specified in the County's Request for Proposals or Qualifications (the "RFP") "RFP Number 5219 for "stream buffer study" issued May 24, 2016, and the Provider's proposal, which are fully incorporated and integrated herein by reference together with Attachments 1, RFQ#5219 and Attachment 2, the response provided by Provider (designate all attachments). In the event a term or condition in any document or attachment conflicts with a term or condition of this Agreement the term or condition in this Agreement shall control. Should such conflict arise the priority of documents shall be as follows: This Agreement, the County's RFP together with attachments, Provider's Proposal together with attachments. ii) The Basic Services will be performed by the Provider in accordance with the following schedule: (Insert task list and milestone dates) Task Milestone Date 1. Evaluate existing regulations August 31, 2016 Revised 6/16 2 2. Conduct Field Surveys August 31 through September 16, 2016 3. Complete soil borings August 31 through September 16, 2016 4. Test soil and develop models September 9 through September 19, 2016 5. Develop evaluation model September 9 through September 19, 2016 6. Assess buffer needs September 16 through September 21, 2016 7. Finalize report with County staff September 23 through 28, 2016 8. Submit to State (with County Approval) September 30, 2016 9. Prepare for EMC Meeting Month of October 2016 10. Attend EMC Meeting and assist County with presentation Date to be Determined iii) Should County reasonably determine that Provider has not met the Milestone Dates established in Section 3(a)(ii), County shall notify Provider of the failure to meet the Milestone Date. The County, at its discretion may provide the Provider seven (7) days to cure the breach. County may withhold the accompanying payment without penalty until such time as Provider cures the breach. In the alternative, upon Provider's failure to meet any Milestone Date the County may modify the Milestone Date schedule. Should Provider or its representatives fail to cure the breach within seven (7) days, or fail to reasonably agree to such modified schedule, County may immediately terminate this Agreement in writing, without penalty or incurring further obligation to Provider. This section shall not be interpreted to limit the definition of breach to the failure to meet Milestone Dates. 4. Duration of Services a. Term. The term of this Agreement shall be from August 1, 2016 to December 30, 2016. b. Scheduling of Services i) The Provider shall schedule and perform its activities in a timely manner so as to meet the Milestone Dates listed in Section 3. ii) Should the County determine that the Provider is behind schedule, it may require the Provider to expedite and accelerate its efforts, including providing additional resources and working overtime, as necessary, to perform its services in accordance with the approved project schedule at no additional cost to the County. Revised 6/16 3 iii) The Commencement Date for the Provider's Basic Services shall be August 1, 2016. 5. Compensation a. Compensation for Basic Services. Compensation for Basic Services shall include all compensation due the Provider from the County for all services under this Agreement. The maximum amount payable for Basic Services is Seventy-eight thousand Dollars ($78.000/00). In the event the amount stated on an invoice is disputed by the County, the County may withhold payment of all or a portion of the amount stated on an invoice until the parties resolve the dispute. Payment for Basic Services shall become due and payable in direct proportion to satisfactory services performed and work accomplished. Payments will be made as percentages of the whole as Project milestones as set out in Section 3(a)(ii) are achieved. (For example, if there are 10 Project Tasks with Milestone Dates then Provider may invoice for the first 10% of the whole upon County's acknowledgement of the satisfactory completion of Task one. Upon the County's acknowledgement that the second Task has been satisfactorily completed Provider may invoice for the next 10%of the whole.) b. Additional Services. County shall not be responsible for costs related to any services in addition to the Basic Services performed by Provider unless County requests such additional services in writing and such additional services are evidenced by a written amendment to this Agreement. 6. Responsibilities of the County a. Cooperation and Coordination. The County has designated (Michael D. Harvey) to act as the County's representative with respect to the Project and shall have the authority to render decisions within guidelines established by the County Manager and/or the County Board of Commissioners and shall be available during working hours as often as may be reasonably required to render decisions and to furnish information. 7. Insurance a. General Requirements. Provider shall obtain, at its sole expense, Commercial General Liability Insurance, Automobile Insurance, Workers' Compensation Insurance, and any additional insurance as may be required by County's Risk Manager as such insurance requirements are described in the Orange County Risk Transfer Policy and Orange County Minimum Insurance Coverage Requirements (each document is incorporated herein by reference and may be viewed at http://www.orangecountync.gov/departments/purchasing division/contracts.php). If County's Risk Manager determines additional insurance coverage is required such additional insurance shall consist of N/A (if no additional insurance required mark N/A as being not applicable). Provider shall not commence work until such insurance is in effect and certification thereof has been received by the County's Risk Manager. 8. Indemnity a. Indemnity. The Provider agrees to defend, indemnify and hold harmless the County from all loss, liability, claims or expense, including attorney's fees, arising out of or Revised 6/16 4 related to the Project and arising from bodily injury including death or property damage to any person or persons caused in whole or in part by the negligence or misconduct of the Provider except to the extent same are caused by the negligence or willful misconduct of the County. It is the intent of this provision to require the Provider to indemnify the County to the fullest extent permitted under North Carolina law. 9. Amendments to the Agreement a. Changes in Basic Services. Changes in the Basic Services and entitlement to additional compensation or a change in duration of this Agreement shall be made by a written Amendment to this Agreement executed by the County and the Provider. The Provider shall proceed to perform the Services required by the Amendment only after receiving a fully executed Amendment from the County. 10. Termination a. Termination for Convenience of the County. This Agreement may be terminated without cause by the County and for its convenience upon seven (7) days prior written notice to the Provider. b. Other Termination. The Provider may terminate this Agreement based upon the County's material breach of this Agreement; provided, the County has not taken all reasonable actions to remedy the breach. The Provider shall give the County seven (7) days' prior written notice of its intent to terminate this Agreement for cause. c. Compensation After Termination. i) In the event of termination, the Provider shall be paid that portion of the fees and expenses that it has earned to the date of termination, less any costs or expenses incurred or anticipated to be incurred by the County due to errors or omissions of the Provider. ii) Should this Agreement be terminated, the Provider shall deliver to the County within seven (7) days, at no additional cost, all deliverables including any electronic data or files relating to the Project. d. Waiver. The payment of any sums by the County under this Agreement or the failure of the County to require compliance by the Provider with any provisions of this Agreement or the waiver by the County of any breach of this Agreement shall not constitute a waiver of any claim for damages by the County for any breach of this Agreement or a waiver of any other required compliance with this Agreement. e. Suspension. County may suspend the Services at any time for County's convenience and without penalty to County upon three (3) days' notice to Provider. Upon any suspension by County, Provider shall discontinue the work and shall not resume the work until notified to proceed by County. 11. Additional Provisions Revised 6116 5 a. Limitation and Assignment. The County and the Provider each bind themselves, their successors, assigns, and legal representatives to the terms of this Agreement. Neither the County nor the Provider shall assign or transfer its interest in this Agreement without the written consent of the other. b. Governing Law. This Agreement and the duties, responsibilities, obligations, and rights of respective parties hereunder shall be governed by the laws of the State of North Carolina. By executing this Agreement Provider affirms that Provider and any subcontractors of Provider are and shall remain in compliance with Article 2 of Chapter 64 of the North Carolina General Statutes. By executing this Agreement Provider certifies that Provider has not been identified, and has not utilized the services of any agent or subcontractor, on the list created by the State Treasurer pursuant to G.S. 147- 86.58. c. Anti-Discrimination. Provider shall at all times remain in compliance with all applicable local, state, and federal laws, rules, and regulations. Provider shall at all times remain in compliance with all applicable local, state, and federal laws, rules, and regulations including but not limited to all state and federal anti-discrimination laws, policies, rules, and regulations and the Orange County Anti-Discrimination Policy. Any violation of this requirement is a breach of this Agreement and County may immediately terminate this Agreement without further obligation on the part of the County. This paragraph is not intended to limit and does not limit the definition of breach to discrimination. d. Dispute Resolution. Any and all suits or actions to enforce, interpret or seek damages with respect to any provision of, or the performance or non-performance of, this Agreement shall be brought in the General Court of Justice of North Carolina sitting in Orange County, North Carolina. It is agreed by the parties that no other court shall have jurisdiction or venue with respect to such suits or actions. Binding arbitration may not be initiated by either Party, however, the Parties may agree to nonbinding mediation of any dispute prior to the bringing of such suit or action. e. Entire Agreement. This Agreement, together with the RFP and its attachments and the Proposal and its attachments, represents the entire and integrated agreement between the County and the Provider and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both parties. Modifications may be evidenced by facsimile signatures. f. Severability. If any provision of this Agreement is held as a matter of law to be unenforceable, the remainder of this Agreement shall be valid and binding upon the Parties. g. Ownership of Work Product. Should Provider's performance of this Agreement generate documents, items, or things that are specific to this Project such documents, items or things shall become the property of the County and may be used on any other project without additional compensation to the Provider. The use of the documents, items or things by the County or by any person or entity for any purpose other than the Project as set forth in this Agreement shall be at the full risk of the County. Revised 6/16 6 h. Non-Appropriation. Provider acknowledges that County is a governmental entity, and the validity of this Agreement is based upon the availability of public funding under the authority of its statutory mandate. In the event that public funds are unavailable and not appropriated for the performance of County's obligations under this Agreement, then this Agreement shall automatically expire without penalty to County immediately upon written notice to Provider of the unavailability and non-appropriation of public funds. It is expressly agreed that County shall not activate this non-appropriation provision for its convenience or to circumvent the requirements of this Agreement, but only as an emergency fiscal measure during a substantial fiscal crisis. In the event of a change in the County's statutory authority, mandate and/or mandated functions, by state and/or federal legislative or regulatory action, which adversely affects County's authority to continue its obligations under this Agreement, then this Agreement shall automatically terminate without penalty to County upon written notice to Provider of such limitation or change in County's legal authority. i. Signatures. This Agreement together with any amendments or modifications may be executed electronically. All electronic signatures affixed hereto evidence the intent of the Parties to comply with Article 11A and Article 40 of North Carolina General Statute Chapter 66. j. Notices. Any notice required by this Agreement shall be in writing and delivered by certified or registered mail,return receipt requested to the following: Orange County Provider's Name &Address Attention: Michael Harvey Michael Calhoun -V and M P.O. Box 8181 1318 - F Patton Avenue Hillsborough, NC 27278 Ashville, NC 28806 [SIGNATURE PAGE TO FOLLOW] Revised 6/16 7 IN WITNESS WHEREOF, the Parties, by and through their authorized agents, have hereunder set their hands and seal, all as of the day and year first above written. ORANGE COUNTY: PROVIDER: By: Z By: m�aj Q - CAZ&eyll County Manager Michael Calhoun-Vice President Vaughn and Melton Consulting Engineers Printed name and title Revised 6/16 8