HomeMy WebLinkAbout2014-123 Planning - Park Construction of NC Inc for McGowan Sewer Interceptor Construction $597,813 v�41- iz15
��aNNiN l
5A
CONTRACT DOCUMENTS
McGOWAN INTERCEPTOR
I
I
ORANGE COUNTY, NORTH CAROLINA
SRF PROJECT NO. CS370884-02
C® s �- �� aN
5 e e_ tear -V r.� t
a � -f-
i
OMcGill
ASSOCIATES
CONSUL, 1 iNG ENGINEERS
HICKORY, NORTH CAROLINA
i
i
i
I
�I
i
IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement. Counterparts have been
delivered to Owner and Contractor. All portions of the Contract Documents have been signed or have been
identified by Owner and Contractor or on their behalf.
OWNER: CONTRACTOR
Orange County Park Construction of NC,Inc.
By: R By: Kenneth T.Malonson
Title:7 ' GA Cut& -pO« Title: Vice President
(If Contractor is a corporation,a_partncrship,or a
joint venture,attach evidence of authority to sign.)
n
r
Attest: Attest: � —
Title:' Title:
Address for giving notices: Address for giving notices:
Orange County Park Construction of NC,Inc.
200 South Cameron Street(PO Box 8181) Post Office Box 500
Hillsborough,North Carolina 28278 Morrisville,North Carolina 27560
License No.: 61200
Pre-Audit Statement: This instrument has been
preaudited in the manner required by the Local
Budget and Fiscal Control Act as amended. Agent for service of process:
By a1&Yw
Title: G
Date: /4
Approved as to Form:
By: * R w
Title: St�.CF eul
Date:
EJCDC C-520 Modified Form of Agreement Between Owner and Contractor for Construction Contract(Stipulated Price)
Copyright®2007 National Society of Professional Engineers for EJCDC.All rights reserved.
k=
Page 7 of 7
. . .
Please return this copytotheOerktotheBoand's
--
����
BOND NO. 106008100 r^=�°~~—�f�ceforpernnanentaQenda �|e.
PERFORMANCE Bvmi,4"
Any singular reference 10 Contractor, Surety,Owner, or other party mbuU he considered plural where applicable.
CONTRACTOR(Name andAddress): SURETY(Name. and Address of Principal Place�B���):
PARK CONSTRUCTION OF NORTH TRAVELERS C/\8UALTYAND �URETYCOK8PAN ' OFA&1ER|CA
CAROLINA, INC, 35O GRANITE STREET
PO BOX 500, K4ORR|5V|LLE, NC 27560 BRAINTREE, MA 02184
OWNER(Name undAudreux):
ORANGE COUNTY
200 S. CAMERON STREET(P.0, BOX 8181)
H|LLSBORDU8H, NC. 28278
CONTRACT
{Iffeotb/o Date ofAgreement:
Amount: $597.813.13
Description (Name onJlocu/ion): K4o6OWAN INTERCEPTOR
BOND
Bond Number: 106088190
Date (Not earlier than Effective Date of
Agreement):
Amount: $597.81313
Modifications to this Bond Form: NONE
Surety and Contractor, intending tohe legally bound hereby, subject k/the tcmua set forth below, do each cause
this Performance Bond to be duly executed by an authorized officer, agent, or representative.
CONTRACTOR AS PRINCIPAL 80RIKTY
PARK CONSTRUCTION OF NORTH TRAVELERS CASUALTY AND SURETY COMPANY
CWROL|NA INC, u|)
to
Signature Xigna—ture(Attach Power of Attorney)
KENNETH T. K8ALON80N E. A. MORR|8SETTE
Print Name Print Name
VICE PRESIDENT ATTORNEY-IN-FACT
Tide Ih|�
Attest: - &t�'ut�
S. B. KELLY,
ATTORNEY-|N-FACT `
/u/o ' /u/e
/&//o: Provide execution 6v additional parties, such oxjobn/venturers, if necessary.
EJcmcc-6m Performance Bond
Prepared ux the Engineers Joint Contract Documents Committee.
Page 1 of3
Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators,
successors, and assigns to Owner for the performance of the Contract, which is incorporated herein by
reference.
1. If Contractor performs the Contract, Surety and Contractor have no obligation under this Bond, except to
participate in conferences as provided in Paragraph 2.1.
2. If there is no Owner Default, Surety's obligation under this Bond shall arise after:
2.1 Owner has notified Contractor and Surety, at the addresses described in Paragraph 9 below, that
Owner is considering declaring a Contractor Default and has requested and attempted to arrange a
conference with Contractor and Surety to be held not later than 15 days after receipt of such notice
to discuss methods of performing the Contract. If Owner, Contractor, and Surety agree, Contractor
shall be allowed a reasonable time to perform the Contract, but such an agreement shall not waive
Owner's right, if any, subsequently to declare a Contractor Default; and
2.2 Owner has declared a Contractor Default and formally terminated Contractor's right to complete
the Contract. Such Contractor Default shall not be declared earlier than 20 days after Contractor
and Surety have received notice as provided in Paragraph 2.1; and
2.3 Owner has agreed to pay the Balance of the Contract Price to:
1. Surety in accordance with the terms of the Contract; or
2. Another contractor selected pursuant to Paragraph 3.3 to perform the Contract.
3. When Owner has satisfied the conditions of Paragraph 2, Surety shall promptly, and at Surety's expense,
take one of the following actions:
3.1 Arrange for Contractor, with consent of Owner,to perform and complete the Contract; or
3.2 Undertake to perform and complete the Contract itself, through its agents or through independent
contractors; or
3.3 Obtain bids or negotiated proposals from qualified contractors acceptable to Owner for a contract
for performance and completion of the Contract, arrange for a contract to be prepared for execution
by Owner and contractor selected with Owner's concurrence, to be secured with performance and
payment bonds executed by a qualified surety equivalent to the bonds issued on the Contract, and
pay to Owner the amount of damages as described in Paragraph 5 in excess of the Balance of the
Contract Price incurred by Owner resulting from Contractor Default; or
3.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and
with reasonable promptness under the circumstances:
1. After investigation, determine the amount for which it may be liable to Owner and, as soon as
practicable after the amount is determined,tender payment therefor to Owner; or
2. Deny liability in whole or in part and notify Owner citing reasons therefor.
4. If Surety does not proceed as provided in Paragraph 3 with reasonable promptness, Surety shall be
deemed to be in default on this Bond 15 days after receipt of an additional written notice from Owner to
Surety demanding that Surety perform its obligations under this Bond, and Owner shall be entitled to enforce
any remedy available to Owner. If Surety proceeds as provided in Paragraph 3.4, and Owner refuses the
payment tendered or Surety has denied liability, in whole or in part, without further notice Owner shall be
entitled to enforce any remedy available to Owner.
5. After Owner has terminated Contractor's right to complete the Contract, and if Surety elects to act under
Paragraph 3.1, 3.2, or 3.3 above, then the responsibilities of Surety to Owner shall not be greater than those
of Contractor under the Contract, and the responsibilities of Owner to Surety shall not be greater than those
of Owner under the Contract. To the limit of the amount of this Bond, but subject to commitment by Owner
of the Balance of the Contract Price to mitigation of costs and damages on the Contract, Surety is obligated
without duplication for:
EJCDC C-610 Performance Bond
Prepared by the Engineers Joint Contract Documents Committee.
Page 2 of 3
5.1 The responsibilities of Contractor for correction of defective Work and completion of the Contract;
5.2 Additional legal, design professional, and delay costs resulting from Contractor's Default, and
resulting from the actions of or failure to act of Surety under Paragraph 3; and
5.3 Liquidated damages, or if no liquidated damages are specified in the Contract, actual damages
caused by delayed performance or non-performance of Contractor.
6. Surety shall not be liable to Owner or others for obligations of Contractor that are unrelated to the
Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such
unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than Owner
or its heirs, executors, administrators, or successors.
7. Surety hereby waives notice of any change, including changes of time, to Contract or to related
subcontracts, purchase orders, and other obligations.
8. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent
jurisdiction in the location in which the Work or part of the Work is located, and shall be instituted within
two years after Contractor Default or within two years after Contractor ceased working or within two years
after Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the
provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to
sureties as a defense in the jurisdiction of the suit shall be applicable.
9. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the address shown on the signature
page.
10. When this Bond has been furnished to comply with a statutory requirement in the location where the
Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be
deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed
incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common
law bond.
11. Definitions.
11.1 Balance of the Contract Price: The total amount payable by Owner to Contractor under the
Contract after all proper adjustments have been made, including allowance to Contractor of any
amounts received or to be received by Owner in settlement of insurance or other Claims for
damages to which Contractor is entitled, reduced by all valid and proper payments made to or on
behalf of Contractor under the Contract.
11.2 Contract: The agreement between Owner and Contractor identified on the signature page,
including all Contract Documents and changes thereto.
11.3 Contractor Default: Failure of Contractor, which has neither been remedied nor waived, to perform
or otherwise to comply with the terms of the Contract.
11.4 Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor
as required by the Contract or to perform and complete or otherwise comply with the other terms
thereof.
FOR INFORMATION ONLY—(Name,Address and Telephone) IIA, INC. DBA INFANTINE INSURANCE
Surety Agency or Broker: P.O. BOX 5125, MANCHESTER, NH 03108
Owner's Representative(Engineer or other party): 603-669-0704
EJCDC C-610 Performance Bond
Prepared by the Engineers Joint Contract Documents Committee.
Page 3 of 3
. . '
BOND NO, 106008190
PAYMENTBOND
Any singular reference to Contractor, Surety,Owner, or other party shall be considered plural where applicable.
CONTRACTOR(Name undAddrn ): SURETY(Namm' and Address of Principal Place of
PARK CONSTRUCTION OF NORTH Business): TRAVELERS CASUALTY AND SURETY
CAROLINA, INC, COMPANY OF AMERICA
PD. BOX 50O. K8ORR|8V|LLE. NC275GO 350 GRANITE STREET
OWNER(Name ood^4ubresa): BRAINTREE, K4A02184
ORANGE COUNTY '
2OO8. CAMERON STREET(PD. BOX 8181)
GH, N.C, 28278
Effective Date ofAgreement:
Amount: $597.81313
Description (Nanveuxdl000doo): K4cGDVVAN INTERCEPTOR
BOND
Bond Number: 106008180
Date (Not earlier than Effective Date m/
Agreement):
Amount: $597.81313
Modifications to this Bond Form: NONE
Surety and Contractor, intending to be legally bound hereby, subject tothe terms set forth below, do each
cause this Payment Bond tohc duly executed hyoo authorized offioer, agent, orrepresentative.
CONTRACTOR AS PRINCIPAL SURETY
PARK CONSTRUCT/ON OF NORTH TRAVELERS CASUALTY AND SURETY COMPANY
CAROLINA, INC. (
Contractor's Name and Corporate Seal 'sNa d C ate Seal
Signature ignature (Attach Power of Attorney)
KENNETHTMALONSON EA. K4ORR|3SETTE
Print Name Print Name
VICE PRESIDENT ATTORNEY-|N-FACT
Title Title
Attest: -- Attest: r- -kM
Title Title
Note: Provide execution/y additional parties, such ox'oin/venturers, if necessary.
(MWO01504;1) EJCDC C-615(A)Payment Bond March 2008
Prepared on the Engineers Joint Contract Documents Committee.
Pagel of`3
1. Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators,
successors, and assigns to Owner to pay for labor, materials, and equipment furnished by Claimants for use
in the performance of the Contract, which is incorporated herein by reference.
2. With respect to Owner, this obligation shall be null and void if Contractor:
2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and
2.2 Defends, indemnifies, and holds harmless Owner from all claims, demands, liens, or suits alleging
non-payment by Contractor by any person or entity who furnished labor, materials, or equipment
for use in the performance of the Contract, provided Owner has promptly notified Contractor and
Surety (at the addresses described in Paragraph 12) of any claims, demands, liens, or suits and
tendered defense of such claims, demands, liens, or suits to Contractor and Surety, and provided
there is no Owner Default.
3. With respect to Claimants, this obligation shall be null and void if Contractor promptly makes payment,
directly or indirectly, for all sums due.
4. Surety shall have no obligation to Claimants under this Bond until:
4.1 Claimants who are employed by or have a direct contract with Contractor have given notice to
Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to Owner,
stating that a claim is being made under this Bond and,with substantial accuracy, the amount of the
claim.
4.2 Claimants who do not have a direct contract with Contractor:
1. Have furnished written notice to Contractor and sent a copy, or notice thereof, to Owner, within
90 days after having last performed labor or last furnished materials or equipment included in the
claim stating, with substantial accuracy, the amount of the claim and the name of the party to
whom the materials or equipment were furnished or supplied, or for whom the labor was done or
performed; and
2. Have either received a rejection in whole or in part from Contractor, or not received within 30
days of furnishing the above notice any communication from Contractor by which Contractor had
indicated the claim will be paid directly or indirectly; and
3. Not having been paid within the above 30 days, have sent a written notice to Surety (at the
address described in Paragraph 12) and sent a copy, or notice thereof, to Owner, stating that a
claim is being made under this Bond and enclosing a copy of the previous written notice
furnished to Contractor.
5. If a notice by a Claimant required by Paragraph 4 is provided by Owner to Contractor or to Surety, that is
sufficient compliance.
6. Reserved.
7. Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be
credited for any payments made in good faith by Surety.
8. Amounts owed by Owner to Contractor under the Contract shall be used for the performance of the
Contract and to satisfy claims, if any, under any performance bond. By Contractor furnishing and Owner
accepting this Bond, they agree that all funds earned by Contractor in the performance of the Contract are
dedicated to satisfy obligations of Contractor and Surety under this Bond, subject to Owner's priority to use
the funds for the completion of the Work.
9. Surety shall not be liable to Owner, Claimants, or others for obligations of Contractor that are unrelated
to the Contract. Owner shall not be liable for payment of any costs or expenses of any Claimant under this
Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of, or
otherwise have obligations to Claimants under this Bond.
{MW001504;1} EJCDC C-615(A)Payment Bond March 2008
Prepared by the Engineers Joint Contract Documents Committee.
Page 2 of 3
10. Surety hereby waives notice of any change, including changes of time, to the Contract or to related
subcontracts, purchase orders, and other obligations.
11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent
jurisdiction in the location in which the Work or part of the Work is located or after the expiration of one
year from the date (1) on which the Claimant gave the notice required by Paragraph 4.1 or Paragraph 4.2.3,
or (2) on which the last labor or service was performed by anyone or the last materials or equipment were
furnished by anyone under the Contract, whichever of (1) or (2) first occurs. If the provisions of this
paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense
in the jurisdiction of the suit shall be applicable.
12. Notice to Surety, Owner, or Contractor shall be mailed or delivered to the addresses shown on the
signature page. Actual receipt of notice by Surety, Owner, or Contractor, however accomplished, shall be
sufficient compliance as of the date received at the address shown on the signature page.
13. When this Bond has been furnished to comply with a statutory requirement in the location where the
Contract was to be performed, any provision in this Bond conflicting with said statutory requirement shall be
deemed deleted herefrom and provisions conforming to such statutory requirement shall be deemed
incorporated herein. The intent is that this Bond shall be construed as a statutory Bond and not as a common
law bond.
14. Upon request of any person or entity appearing to be a potential beneficiary of this Bond, Contractor
shall promptly furnish a copy of this Bond or shall permit a copy to be made.
15. Definitions
15.1 Claimant: An individual or entity having a direct contract with Contractor, or with a first-tier
subcontractor of Contractor, to furnish labor, materials, or equipment for use in the performance of
the Contract. The intent of this Bond shall be to include without limitation in the terms "labor,
materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service,
or rental equipment used in the Contract, architectural and engineering services required for
performance of the Work of Contractor and Contractor's subcontractors, and all other items for
which a mechanic's lien may be asserted in the jurisdiction where the labor, materials, or
equipment were furnished.
15.2 Contract: The agreement between Owner and Contractor identified on the signature page,
including all Contract Documents and changes thereto.
15.3 Owner Default: Failure of Owner, which has neither been remedied nor waived, to pay Contractor
as required by the Contract, or to perform and complete or otherwise comply with the other terms
thereof.
FOR INFORMATION ONLY—(Name,Address, and Telephone) IIA, INC DBA INFANTINE INSURANCE
Surety Agency or Broker: P.O. BOX 5125, MANCHESTER, NH 03108
Owner's Representative(Engineer or other): 603-669-0704
(MW001504;1) EJCDC C-615(A)Payment Bond March 2008
Prepared by the Engineers Joint Contract Documents Committee.
Page 3 of 3
WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER
POWER OF ATTORNEY
TRAVELERSJ Farmington Casualty Company St.Paul Mercury Insurance Company
Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company
Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America
St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company
St.Paul Guardian Insurance Company
Attorney-In Fact No. 227015 Certificate No. 005597510
KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance
Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States
Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a
corporation duly organized under the laws of the State of Iowa,and that Fidelity and Guaranty Insurance Underwriters,Inc.,is a corporation duly organized under the
laws of the State of Wisconsin(herein collectively called the"Companies"),and that the Companies do hereby make,constitute and appoint
J.Harrison,C.H.Hamlin,P.L.Sullivan,E.A.Morrissette,J.J.Schroeder,and S.B.Kelly
of the City of Bedford State of Now Hlmpshlre their true and lawful Attorney(s)-in-Fact,
each in their separate capacity if more than one is named above,to sign,execute,seal and acknowledge any and all bonds,recognizances,conditional undertakings and
other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of
contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
IN WITNESS WHEREOF,the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed,this 13th
day of August 2013
Farmington Casualty Company St.Paul Mercury Insurance Company
Fidelity and Guaranty Insurance Company Travelers Casualty and Surety Company
Fidelity and Guaranty Insurance Underwriters,Inc. Travelers Casualty and Surety Company of America
St.Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company
p�y St.Paul Guardian Insurance Company
CASUA�� pyr•••� Jy�\0.E R,w.,_ O��,µMKSU9 �JC'j'Ng✓/g2 9JP[Y ANO 9` ��1r���h� �,�,�Y�
�S '�Jei n CTV- � RAtFD a� _ y-cT �oavon f m �W w f°" ° 9 5 HpIttF6
Z619>i2 0 1977 � ji inf ii :os a HA�F� � t��cauiAD' £ N �s�<
���a � 1951 ;.sear,,o �o•.58AL;'s W i �
State of Connecticut By:
City of Hartford ss. Robert L.Raney, enior Vice President
On this the 13th day of August 2013 before me personally appeared Robert L.Raney,who acknowledged himself to
be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,St.Paul
Fire and Marine Insurance Company,St.Paul Guardian Insurance Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers
Casualty and Surety Company of America,and United States Fidelity and Guaranty Company,and that he,as such,being authorized so to do,executed the foregoing
instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer.
In Witness Whereof,I hereunto set my hand and official seal. eg* �)My Commission expires the 30th day of June,2016. Marie C.Tetreault,Notary Public
58440-8-12 Printed in U.S.A.
WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER
WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER
This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Farmington Casualty Company,Fidelity
and Guaranty Insurance Company,Fidelity and Guaranty Insurance Underwriters,Inc.,St.Paul Fire and Marine Insurance Company,St.Paul Guardian Insurance
Company,St.Paul Mercury Insurance Company,Travelers Casualty and Surety Company,Travelers Casualty and Surety Company of America,and United States
Fidelity and Guaranty Company,which resolutions are now in full force and effect,reading as follows:
RESOLVED,that the Chairman,the President,any Vice Chairman,any Executive Vice President,any Senior Vice President,any Vice President,any Second Vice
President,the Treasurer,any Assistant Treasurer,the Corporate Secretary or any Assistant Secretary may appoint Attorneys-in-Fact and Agents to act for and on behalf
of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the
Company's seal bonds,recognizances,contracts of indemnity,and other writings obligatory in the nature of a bond,recognizance,or conditional undertaking,and any
of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her;and it is
FURTHER RESOLVED,that the Chairman,the President,any Vice Chairman,any Executive Vice President,any Senior Vice President or any Vice President may
delegate all or any part of the foregoing authority to one or more officers or employees of this Company,provided that each such delegation is in writing and a copy
thereof is filed in the office of the Secretary;and it is
FURTHER RESOLVED,that any bond,recognizance,contract of indemnity,or writing obligatory in the nature of a bond,recognizance,or conditional undertaking
shall be valid and binding upon the Company when(a)signed by the President,any Vice Chairman,any Executive Vice President,any Senior Vice President or any Vice
President,any Second Vice President,the Treasurer,any Assistant Treasurer,the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the
Company's seal by a Secretary or Assistant Secretary;or(b)duly executed(under seal,if required)by one or more Attorneys-in-Fact and Agents pursuant to the power
prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is
FURTHER RESOLVED,that the signature of each of the following officers:President,any Executive Vice President,any Senior Vice President,any Vice President,
any Assistant Vice President,any Secretary,any Assistant Secretary,and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any
certificate relating thereto appointing Resident Vice Presidents,Resident Assistant Secretaries or Attorneys-in-Fact for purposes only of executing and attesting bonds
and undertakings and other writings obligatory in the nature thereof,and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal
shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on
the Company in the future with respect to any bond or understanding to which it is attached.
I,Kevin E.Hughes,the undersigned,Assistant Secretary,of Farmington Casualty Company,Fidelity and Guaranty Insurance Company,Fidelity and Guaranty Insurance
Underwriters,Inc.,St.Paul Fire and Marine Insurance Company,St.Paul Guardian Insurance Company,St.Paul Mercury Insurance Company,Travelers Casualty and
Surety Company,Travelers Casualty and Surety Company of America,and United States Fidelity and Guaranty Company do hereby certify that the above and foregoing
is a true and correct copy of the Power of Attorney executed by said Companies,which is in full force and effect and has not been revoked.
IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed the seals of said Companies this day of 29/y
iW�
Kevin E.Hughes,Assistant Sec tart'
ASV F1PE 6 �N �Nf {iN54q JpISY qy� �°i ��IW
n
L!$o o6:�S8bLie W ro `V '�`
��
To verify the authenticity of this Power of Attorney,call 1-800-421-3880 or contact us at www.travelersbond.com.Please refer to the Attorney-In-Fact number,the
above-named individuals and the details of the bond to which the power is attached.
WARNING:THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER