Loading...
HomeMy WebLinkAbout2004 S Housing - Consolidated Housing Plan Annual Update/HOME Program Signed Agreement with Orange Community Housin & Land Trust Incs- ~-a~ s-y NORTH CAROLINA ORANGE COUNTY DEVELOPMENT AGREEMENT This is an AGREEMENT between ORANGE COUNTY, NORTH CAROLINA, a general local governmental unit of the State of North Carolina, (hereinafter referred to as the "Count}') and Orange Community Housing and Land Trust, Inc., a North Carolina non- profit a oration (hereinafter referred to as "OCHLT"). The effective date of this agreement is 00 WITNESSETH WHEREAS, the Orange County HOME Consortium has designated $70,000 in FY 2004 HOME funds and $15,000 in FY 2005 HOME Funds for the purpose of subsidizing homes in the Pacifica co-housing development in Carrboro for sale to eligible first-time homebuyers hereinafter referred to as the "Project"; and WHEREAS, the County is the lead entity of the Orange HOME Consortium, so designated in an agreement dated July 1, 2005 and as such is the lead entity in a representative capacity for all members of the Orange HOME Consortium for the purposes of carrying out the HOME Program in accordance with the Title II of the Cranston-Gonzalez National Affordable Housing Act (Pub. L. 101-625), (42 U.S.C. 3535(d.) et. ~.) (hereinafter referred to as the "Act"), and as further defined in the Federal Program Requirements provided by the U.S. Department of Housing and Urban Development; and WHEREAS, Orange Community Housing and Land Trust (OCHLT) is a designated. Community Housing Development Corporation (CHDO) as defined in 24 CCR Part 92, Subpart A, Section 92.2 interested in serving as sponsor, developer, and/or advocate for potential first- time homebuyers; and WHEREAS, afirst-time homebuyer for the purposes of this program is defined as any household earning up to 80% of HUD area median income that has not owned a home within the past three (3) years including households living in manufactured housing not permanently affixed to a foundation, or owner-occupants of homes not feasible for rehabilitation; and WHEREAS, OCHLT intends to purchase the Project dwelling units and make them available for sale to families earning up to 80% of HUD area median income as described in the OCHLT 2004 and 2005 HOME Program Applications which applications are incorporated by reference into this Agreement. The OCHLT 2004 and 2005 HOME Program Applications are on file in the office of the Orange County Department of Housing and Community Development. 1 NOW, THEREFORE, in consideration of the mutual covenants, promises, and representations contained herein, it is agreed between the parties hereto as follows: 1. OCHLT agrees to acquire and resale the Project dwelling units in the following manner. a. The seven (7) prospective dwelling units (dwellings) to be purchased have obtained a Certificate of Occupancy. b. If any of the Project dwelling units fail to meet Section 8 Housing Quality Standards (HQS) and repairs are necessary, OCHLT is responsible that the work is done properly and in accordance with all applicable laws and local ordinances. Before resale, each Project dwelling unit must meet the Section 8 Housing Quality Standards and local Minimum Housing Code at a minimum. c. OCHLT will purchase two (2) dwelling units for $76,100 and sell them for $66,100; two (2) dwelling units for $104,150 and sell them for $94,150; two (2) dwelling units for $118,000 and sell them for $103,000; and one dwelling unit for $126,000 and sold for $111,000. d. Upon resale, OCHLT must provide to the Orange County Housing and Community Development Offiice certification that the property was sold to a family whose income does not exceed 80% of area median income and provide information regarding family characteristics asrequested. 2. OCHLT shall convey each of the Project dwelling units to a first-time homebuyer with income 80% or less of the area median household income by family size, as determined by the U.S. Department of Housing and Urban Development at the time of the sale. A housing unit will consist of a 99-year ground lease (renewable f'or an additiona199 years) to the housing unit and a warranty deed to the improvements on the leased premises. 3. The period of affordability will be 99 years and will be secured by an OCHLT Ground Lease with restrictions to ensure compliance. Further security shall be in the form of a Declaration of Restrictive Covenants that will make the County a third party beneficiary of and successor to the long term affordability remedies in the Ground Lease in the event of a failure of or inability of OCHLT to enforce the long-term affordability remedies in the Ground Lease. 4. OCHLT is responsible for soliciting buyers for the Project dwelling units constructed on the Property. OCHLT andlor its buyers shall be responsible for securing permanent mortgage financing for the homes built on the Property. 5. OCHLT is responsible for verifying the income of the homebuyers and explaining the OCHLT Ground Lease to potential homebuyers and certifying by written documentation signed by the homebuyer that the HOME program requirements have been fully explained. OCHLT shall maintain purchaser files as part of its Books and Records as required and for the period of time required by Section 10.c. of this Agreement. 2 6. The property must have a value that does not exceed 95% of the area median purchase price for that type of housing. Value must be established by one of the following methods: i. An appraisal by a qualified appraiser. ii. Tax assessments may be used to establish value, but only if they are current and can be computed at 100% of market value. 7. Time for Commencement and Completion. The Project must begin within one (1) year of the date of this Agreement. OCHLT will be responsible for providing status reports to the County quarterly detailing the project activities until project completion. In addition, OCHLT agrees to furnish to the County a copy of its annual audit performed by a certified public accountant within 90 days of the end of each fiscal year until the Project is complete. The Project completion date is the closing date of the purchase by a qualified buyer of the last of the Project dwelling units. In the event that OCHLT is unable to proceed with any aspect of the project in a timely manner, and County and OCHLT determine that reasonable extension(s) for completion will not remedy the situation, then the Termination of Agreement provisions of this Agreement (Section 10.a.) shall pertain. OCHLT may, at its option, submit a written request for a delay of completion for County approval. The County may, at its option, approve any delay in the completion date or declare OCHLT in default. OCHLT shall monitor the dwelling units for affordability for the period of affordability - ninety-nine (99) years. Final contract completion date shall be the end date of the last affordability period. 8. Affordability Requirement. Each of the Project dwelling units must remain affordable for a period of ninety-nine years. OCHLT retains full responsibility for compliance with the affordability requirement for each of the dwelling units, unless affordability restrictions are terminated due to the sale of the Property to anon-qualified buyer in which event the Resale Provisions of Section 9 of this Agreement pertain. OCHLT shall assure compliance with affordability of each of the dwelling units by having recorded a "Declaration of Restrictive Covenants" (EXHIBIT A) on the Property. This Declaration shall constitute and remain a first lien on the Property during the period of affordability. It is further the responsibility of OCHLT to rerecord the Declaration of Restrictive Covenants no later than one day before the expiration of 30 years of the date of the purchase of the Property in the event that OCHLT is still the owner of the Project dwelling units at the time of the rerecording. County retains the right to periodically and every 30 years after the first recording of the Declaration of Restrictive Covenants on the Property to register, with the Register of Deeds of Orange County, a notice of preservation of the Restrictive Covenants on the Property as provided in North Carolina 3 General Statute § 47B-4 or any comparable preservation law in effect at the time of the recording of the notice of preservation. It is the intent of this Section of this Agreement that the 99 year affordability requirement contained herein be accomplished and that OCHLT and the County will do what is necessary to ensure that the same is not extinguished by N.C. Gen. Stat. § 41-29 or any comparable law purporting to extinguish, by the passage of time, preemptive rights in the Property and by the Real Property Marketable Title Act or any comparable law purporting to extinguish, by the passage of time, non possessory interests in real property. Both OCHLT and County agree to do what each must do to accomplish the 99-year affordability requirement. 9. Resale Provisions. OCHLT shall assure compliance with affordability of dwelling unit through the Declaration of Restrictive Covenants and the Ground Lease. 10. Miscellaneous Provisions. a. Termination of Agreement. The full benefit of the Project will be realized only after the completion of the affordability periods for all dwelling units purchased under this Agreement. It is the County's intention that the full public benefit of the Project shall be completed under the auspices of OCHLT for the assisted units as follows: i. In the event that OCHLT is unable to proceed with any aspect of the Project in a timely manner, and County and OCHLT determine that reasonable extension(s) for completion will not remedy the situation, then OCHLT will retain responsibility for requirements for any dwelling units assisted and County will make no further payments to OCHLT. ii. In the event that OCHLT, prior to the contract completion date, is unable to continue to function due to, but, not limited to, dissolution or insolvency of the organization, its filing a petition for bankruptcy or similar proceedings, or is adjudged bankrupt or fails to comply or perform with provisions of this agreement, then OCHLT shall, upon the County's request, convey to the County the Property assisted with funds. Conveyance shall be at the sole discretion of County and on a dwelling unit by dwelling unit basis. Conveyance shall be on the terms set forth herein: Conveyance shall occur within thirty (30) days of County and OCHLT's agreement of OCHLT's inability to continue as a viable organization. OCHLT shall convey the Property to the County by general warranty deed, free and clear of all liens and encumbrances of record except those which create a beneficial interest in County (Declaration of Restrictive Covenants) and any other agreed. to by County in writing. b. Default, Remedies. This Agreement may be terminated by anon-defaulting party upon an event of default hereunder, after written notice thereof and thirty (30) days grace period in which the defaulting party may act to cure. As used herein, the term "an event of 4 default" shall mean and refer to a failure or act of omission by either party with respect to any undertaking, obligation, covenant or condition as set forth in this Agreement. With respect to any event of default, the non-defaulting party may exercise any right available to it at law or in equity with respect to such default. c. Books and Records. OCHLT shall maintain records of its grant requirements under this contract for a period of not less than five (5) full fiscal years following the contract completion date. i. OCHLT shall ensure access to records and financial statements, as necessary, to provide effective monitoring and evaluation of project performance. Additionally, OCHLT shall submit a copy of its annual audit to the County. Upon reasonable advance notice, County or its authorized representatives may from time to time inspect, audit, and make copies of any of OCHLT's records that relate to this contract. If any audit by County discloses that payments to OCHLT were in excess of the amount to which OCHLT was entitled under this contract, OCHLT shall promptly pay to County the amount of such excess. If the excess is greater than 1% of the contract amount, OCHLT shall also reimburse County its reasonable costs incurred in performing the audit. ii. OCHLT shall maintain files of all purchasers residing in assisted units. Documentation .shall verify eligibility for federal assisted housing at the initial occupancy. Information maintained shall include: tenant income level; name of family members; ethnic data; family type - e.g. female head of household and disability status. iii. OCHLT shall maintain records verifying the affordability of the dwelling units. d. Notices. Any Notice shall be in writing and shall be given by depositing the same in the United States mail, post-paid and registered or certified, and addressed to the party to be notified, with return-receipt requested, or by delivering the same in person to an officer or principal of such party. Notice deposited in the mail in the manner here in above described shall be effective upon mailing. For purposes of Notice, the addresses of the parties shall, unless changed as hereinafter provided, be as follows: i. To the County: Orange County c/o Housing and Community Development Department P.O. Box 8181 Hillsborough, NC 27278 ATTN: Director 5 ii. To OCHLT: Orange Community Housing and Land Trust P.O. Box 307 Carrboro, NC 27510 ATTN: Executive Director Either the County or OCHLT may change the person or address to which any future Notice shall be given as herein provided. e. No Assignment. No transfer or assignment of the interest of OCHLT in this Agreement shall occur without the prior written consent of the County; neither may OCHLT assign this Agreement without the prior written consent of County. f. Conflict of Interest. OCHLT agrees to abide by the provisions of 24 CFR 570.611 with respect to conflicts of interest, and covenants that it presently has no financial interest and shall acquire no financial interest, direct or indirect, that would conflict in any manner or degree with the performance of services required under this Agreement. OCHLT further covenants that in performance of this Agreement no person having such a fmancial interest shall be employed or retained by OCHLT hereunder. These conflicts of interest provisions apply to any person who is an employee, agent, consultant, or elected official or appointed official of the County, or any designated public agencies or subrecipients that are receiving funds under the HOME Investment Partnership Program. f. Binding Effect. This Agreement shall be binding upon and shall inure to the benefit of the parties hereto and their respective successors and assigns. g. .Indemnification. To the extent legally possible, OCHLT shall indemnify and hold County, its officers, agents, and employees, harmless from and against any and all claims, actions, liabilities, costs, including attorney fees and other costs of defense, arising out of or in any way related to any act or failure to act by OCHLT, its employees, agents, officers, and contractors in connection with this contract. In the event any such action or claim is brought against County, OCHLT shall, upon County's tender, defend the same at OCHLT's sole cost and expense, promptly satisfy any judgment adverse to County or to County and OCHLT jointly, and reimburse County for any loss, cost, damage, or expense, including attorney fees suffered or incurred by County. h. Subcontracting. OCHLT shall not subcontract work under this Agreement, in whole or in part, without the County's prior written approval. OCHLT shall require any approved subcontractor to agree, as to the portion subcontracted, to comply with all applicable federal, state, and local laws, rules, ordinances, and regulations at all times and in the performance of the work and to comply with all applicable obligations of OCHLT specified in this contract. Notwithstanding County's approval of a subcontractor, OCHLT shall remain obligated for full performance of this contract and County shall incur no obligation to any subcontractor OCHLT shall indemnify, defend, and hold County harmless from all claims of its contractors. 6 i. No Joint Venture or Agency. The County and OCHLT each agree and acknowledge that nothing contained herein or otherwise, including, without limitation, any act of the County or OCHLT under this Agreement, shall be deemed or construed to create any relationship of joint venture, partnership or agency between the parties. j. Effect of Waiver or Forbearance. No failure by the County to insist upon the strict performance of any term or condition of this Agreement, or to exercise any right or remedy upon the breach by OCHLT of any of its obligations, agreements, or covenants hereunder, shall be a waiver of such affected term or condition or of such breach; nor shall any forbearance by the County to seek a remedy for any breach by OCHLT be a waiver by the County of its rights and remedies with respect to that or any other breach. k. Governing Law. This Agreement shall be construed in accordance with and governed by the laws of the State of North Carolina. Any litigation arising out of this Agreement shall be brought in courts sitting in North Carolina, with venue in Orange County. 1. Severability. The provisions of this Agreement are independent of and separable from each other, and no provision shall be affected or rendered invalid or unenforceable by the fact that for any reason any other provision may be invalid or unenforceable in whole or in part. If any provision of this Agreement or the application thereof to any person or circumstances shall, to any extent, be or become invalid or unenforceable, the remainder of this Agreement, or the application of such provision to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected thereby, and each provision of this Agreement shall be valid and be enforced to the fullest extent permitted by law. The County and OCHLT agree to substitute for such provision of this Agreement or the application thereof determined to be invalid or unenforceable, such other provision as most closely approximates, in a lawful manner, such invalid, illegal or unenforceable provision. If the County and OCHLT cannot agree, they shall apply to a court of competent jurisdiction to substitute such provision as the court deems reasonable and judicially valid, legal and enforceable. Such provision determined by the court shall automatically be deemed part of this Agreement ab initio. m. Equal Opportunity. OCHLT shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, national origin, political affiliation or belief, age, handicap, or familial status in the implementation of the Project. n. Headings. Headings are for convenience only and shall not be used to interpret or construe its provision. o. Gender; Singular and Plural. As used herein, the neuter gender includes the feminine and masculine. The masculine includes the feminine and neuter, and the feminine includes the masculine and neuter and each includes a corporation, partnership or other legal entity when the context so requires. The singular number includes the plural and vice versa, whenever the context so requires. 7 p. Recording. The parties hereto agree that upon notice to the other and at its own cost and expense, a party may record this Agreement in the Office of Register of Deeds for Orange County. q. Compliance with Laws. To the extent applicable, each party hereto agrees to comply with all laws, ordinances and regulations affecting the Property from and after the date hereof. Without limiting the generality of the foregoing, OCHLT shall comply with all federal, state and local laws, regulations and ordinances applicable to the expenditure of funds provided by the County, to purchase and develop the Property. r. Publicity; Signage. OCHLT agrees to provide such publicity with respect to the County's participation in the Project, as the County shall reasonably require. Any signage at the dwelling unit shall acknowledge the County's role and contribution. s. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original but all of which together shall constitute on and the same instrument. t. No Third Party Rights. The parties hereto covenant and agree that nothing contained in this Agreement or any act by the County or OCHLT shall be deemed or construed by the parties or any third party to create any relationship of third party beneficiary, including third party principal or agent, or to create any right, claim or cause of action against the County, OCHLT or any of their respective officers, agents or employees by any third party. u. Performance of Government Functions. Notwithstanding anything in this Agreement which maybe to the contrary, nothing contained in this Agreement shall in any way stop, limit or impair the County from exercising or performing any regulatory, policing or governmental powers or functions with respect to the Property including, without ~ limitation, inspection of the Property in the performance of such functions. IN WITNESS WHEREOF, the parties hereto, intending to be legally bound, have set their hands and seals on the day and yeaz first above written. i i. 4. k ORANGE COUNTY, NORTH CAROLINA John ink, Jr., ounty Manager ATTEST: Do a Baker Clerk to the Boazd of Commissioners Approved as to form and legality Geoffrey Gledhill, County Attorney This document has been preaudited in accordance with the N.C. Local Government and Fiscal Contr ct~ G~\ . ,Kenneth Chavious, Finance Director Orange Community Housing and Land Trust, T_ _ r ~'~ ATTEST 9 Exhibit A Prepared by and return to: Geoffrey E. Gledhill, P.O. Drawer 1529, Hillsborough, NC 27278 DECLARATION OF RESTRICTIVE COVENANTS THIS DECLARATION OF RESTRICTIVE COVENANT'S (Declazation), dated by Orange Community Housing and Land Trust, Inc, and its successors and assigns (Owner), is given as a condition precedent to the award of Federal HOME Investment Partnership Program funds by Orange County, North Cazolina, a body politic and corporate, a political subdivision of the State of North Carolina, (hereafter "the Count') together with any successor to its rights, duties, and obligations. RECITALS: WHEREAS, the Orange County HOME Consortium has designated $70,000 in FY 2004 HOME funds and $15,000 in FY 2005 HOME Funds for the purpose of subsidizing homes in the Pacifica co-housing development in Carrboro for sale to eligible first-time homebuyers hereinafter referred to as the "Project"; and WHEREAS, the County is the lead entity of the Orange HOME Consortium, so designated in an agreement dated July 1, 2005 and as such is the lead entity in a representative capacity for all members of the Orange HOME Consortium for the purposes of carrying out the HOME Program in accordance with the Title II of the Cranston-Gonzalez National Affordable Housing Act (Pub. L. 101-625), (42 U.S.C. 3535(d.) et. se~C .) (hereinafter referred to as the "Act"), and as further defined in the Federal Program Requirements provided by the U.S. Department of Housing and Urban Development; and 10 WHEREAS, Orange Community Housing and Land Trust (OCHLT) is a designated Community Housing Development Corporation (CHDO) as defined in 24 CCR Part 92, Subpart A., Section 92.2 interested in serving as sponsor, developer, and/or advocate for potential first- ti:me homebuyers; and WHEREAS, afirst-time homebuyer for the purposes of this program is defined as any household earning up to 80% of HUD area median income that has not owned a home within the past three (3) years including households living in manufactured housing not permanently affixed to a foundation, or owner-occupants of homes not feasible for rehabilitation; and WHEREAS, OCHLT intends to purchase the Project dwelling units and make them available for sale to families earning up to 80% of HUD area median income as described in the O~CHLT 2004 and 2005 HOME Program Applications which applications are incorporated by reference into this Agreement. The OCHLT 2004 and 2005 HOME Program Applications are on file in the office of the Orange County Department of Housing and Community Development. WHEREAS, as particularly described herein, the Property will be held by OCHLT, ensuring affordability of the homes for at least 99 years; and WHEREAS, OCHLT has signed this Declaration agreeing to the terms of this Declaration, its obligations pursuant to this Declaration and agreeing to the terms of the Development Agreement between the County and OCHLT of even date; and NOW, THEREFORE, in consideration of the mutual covenants, promises, and representations contained herein, it is agreed between the parties hereto as follows: SECTION 1 REPRESENTATIONS, COVENANTS AND WARR.~NTIES OF OWNER OC;HLT hereby represents, covenants and warrants as follows: a. It is contemplated that the Property will be used, during the ninety-nine years after Project Completion, for owner-occupied housing to families earning up to 80% of HUD area median income. In the event Owner sells, transfers or exchanges the Property or any portion of the Property, the following shall pertain: Subject to the requirements of the DEVELOPMENT AGREEMENT, an unsigned copy of which is Exhibit B hereto, and this Declaration, OCHLT may sell, transfer, or exchange the Property to anon-profit fund, foundation, or corporation of like purpose which is organized and operated exclusively for charitable and educational purposes and which has established its tax exempt status under Section 501(c)(3) of the Internal Revenue Code, or to the County, but Owner shall notify in writing and obtain the agreement of any buyer or successor or other person 11 acquiring the Property or any interest therein, that such acquisition is subject to the requirements of this Declaration and to the requirements of the DEVELOPMENT AGREEMENT and the Federal HOME Investment Partnership Program. OCHLT agrees that County may void any sale, transfer, or exchange of the Property or any portion of the Property if the buyer or successor or other person fails to assume in writing the requirements of this Declaration and the requirements of the DEVELOPMENT AGREEMENT. b. OCHLT will, at the time of execution, delivery and recording of this Declaration, have good and marketable title to the Property, free and clear of any lien. or encumbrance (except encumbrances created pursuant to this Declaration or other encumbrances permitted by Orange County). c. OCHLT warrants that it will not accept title to the Property subject to and will not execute any other declaration with provisions contradictory to, or in opposition to, the provisions hereof, and that in any event, the requirements of this Declaration are paramount and controlling as to the rights and obligations herein set forth and supersede any other requirements in conflict herewith. SECTION 2 TERM OF DECLARATION a. This Declaration (and the terms of affordability specified herein) applies to the Property immediately upon the recordation of this Declaration. OCHLT and all subsequent owners of the Property shall comply with all covenants herein. This Declaration shall terminate ninety-nine years after the Project completion date as specified in the DEVELOPMENT AGREEMENT. SECTION 3 RECORDING AND FILING; COVENANTS TO RUN WITH THE LAND a. OCHLT shall cause this declaration and all amendments hereto to be recorded and filed in the Office of the Register of Deeds of Orange County upon its execution. OCHLT shall pay all fees and charges incurred in connection therewith. b. OCHLT intends, declares and covenants, on behalf of itself and all future owners of the Property during the term of this Declaration, that this Declaration and the covenants and restrictions set forth in this Declaration regulating and restricting the use, occupancy and transfer of the Property (1) shall be and are covenants running with the land, encumbering the Property for the term of this Declaration, binding upon all present and future awners of the Property; (2) are not personal covenants of Declarant; and (3) shall bind all present and future owners (and the benefits shall inure to the County and any prospective owner of the Property) and its respective successors and assigns during the term of this Declaration. For the term of this Declaration, each and every contract, deed or other instrument hereafter executed conveying the Property or portion thereof shall expressly provide that such conveyance is subject to this Declaration, provided, however, the covenants contained herein shall survive and be effective regardless of whether such contracts, deed, or other instrument hereafter executed conveying the Property or portion thereof provides that such conveyance is subject to this Declaration. It is further the responsibility 12 OCHLT to rerecord this Declazation periodically and no less often than one day less than every 30 yeazs from the date hereof for the purpose of renewing the rights of first refusal in the Property or portion thereof including any leasehold interest in the Property or portion thereof. The County retains the right to, periodically and every 30 years after the first recording of the ground lease created in Exhibit C hereof, register, with the Register of Deeds of Orange County, a notice of preservation of the Restrictive Covenants on the Property as provided in North Carolina General Statute § 47B-4 or any compazable preservation law in effect at the time of the recording of the notice of preservation. It is the intent of this Section 3 of this Declaration that the 99 yeaz duration of this Declazation of Restrictive Covenants be accomplished and that any future owner of the Property, OCHLT and Orange County will do what is necessary to ensure that the same is not extinguished by N.C. Gen. Stat. § 41-29 or any compazable law purporting to extinguish, by the passage of time, preemptive rights in the Property and by the Real Property Marketable Title Act or any compazable law purporting to extinguish, by the passage of time, non possessory interests in real property. Any future owner of the Property , OCHLT and Orange County will to do what each must do to accomplish the 99 yeaz duration of this Declazation of Restrictive Covenants. SECTION 4 ENFORCEMENT OF AFFORDABLE HOUSING REQUIREMENTS a. Upon completion of construction of the Project, OCHLT will convey a housing unit to each of seven (7) qualified homeowners. Each housing unit will consist of a 99 year ground lease (renewable for an additional 99 yeazs) to the housing unit and a warranty deed to the improvements on the leased premises. The ground lease, the form of which is Exhibit C hereto, provides for the long term affordability (at least 99 years) of the housing unit and provides remedies to insure the long term affordability of the housing unit. OCHLT hereby declares and covenants, on behalf of itself and all future owners of the Property, that, during the term of this Declaration, the County is a third party beneficiary of and successor to each and every remedy intended to insure the long term affordability of the housing unit that is provided for in the ground lease and may, in the event of the failure or default of the Lessor in the ground lease to insure the long term affordability of the housing unit as provided for in the ground lease, exercise all rights and remedies available to the Lessor in the ground lease for that purpose. b. OCHLT covenants that it will not knowingly take or permit any action that would result in a violation of the affordability requirements of the DEVELOPMENT AGREEMENT. Orange County, together with any future owner of the Property may execute acid record any amendment or modification of this Declaration necessary to insure the successful completion of the Project and the long term affordability (at least 99 years) of the housing units on the Property and such amendment or modification shall, to the extent permitted by law, either relate back to the date of recording of this Declaration or not as necessary to carry out the intent of this Declaration, and be binding on third parties granted rights under this Declaration. OCHLT expressly covenants and agrees to rerecord this Declaration periodically and no less often than ane day less than every 30 years from the date hereof for the purpose of renewing the Lessor''s option to purchase and right of first refusal, that are contained in the Exhibit C ground lease, in the Property or portion thereof including any leasehold interest in the Property or portion thereof. 13 c. OCHLT acknowledges that the primary purpose for requiring compliance by OCHLT with restrictions provided in this Declaration is to assure compliance with the long term affordability requirements of the HOME Investment Partnership Program, AND BY REASON THEREOF, OCHLT, IN CONSIDERATION FOR RECENING HOME INVESTMENT PARTNERSHIP PROGRAM FUNDS FOR THE PROPERTY, HEREBY AGREES AND CONSENTS THAT THE COUNTY SHALL BE ENTITLED, FOR ANY BREACH OF THE PROVISIONS HEREIN, AND IN ADDITION TO ALL OTHER REMEDIES PROVIDED BY LAW OR IN EQUITY, TO ENFORCE BY SPECIFIC PERFORMANCE OCHLT'S OBLIGATIONS UNDER THIS DECLARATION IN A STATE COURT OF COMPETENT JURISDICTION, WITH VENUE IN ORANGE COUNTY. OCHLT hereby further specifically acknowledges that the beneficiaries of OCHLT's obligations hereunder cannot be adequately compensated by monetary damages in the event of any default hereunder. If legal costs are incurred by the County, such legal costs, including attorney fees and court costs (including costs of appeal), are the responsibility of, and maybe recovered from the OCHLT. SECTION 5 MISCELLANEOUS a. Severability. The invalidity of any clause, part, or provision of this Declaration shall not affect the validity of the remaining portions thereof. b. Notices. Any Notice shall be in writing and shall be given by depositing the same in the United States mail, post-paid and registered or certified, and addressed to the party to be notified, with return-receipt requested, or by delivering the same in person to an officer or principal of such party. Notice deposited in the mail in the manner herein above described shall be effective upon mailing. For purposes of Notice, the addresses of the parties shall, unless changed as hereinafter provided, be as follows: i. To the County: Orange County c/o Housing and Community Development Department P.O. Box 8181 Hillsborough, NC 27278 ATTN: Director ii. To Declarant: To OCHLT: Orange Community Housing and Land Trust P.O. Box 307 Carrboro, NC 27510 ATTN: Executive Director c. Governing Law. This Declaration shall be governed by the laws of the State of North Cazolina and, where applicable, the laws of the United States of America. IN WITNESS WHEREOF, OCHLT has caused this Declaration to be signed by its duly authorized representative, on the day and year first above written. [SIGNATURES APPEAR ON FOLLOWING PAGE] 14 Orange Community Housing and Land Trust, Inc. By: NORTH CAROLINA ORANGE COUNTY President I, ,Notary Public in and for the above named County and State, do hereby certify that on this day personally appeared before me with whom I am personally acquainted, who, being by me duly sworn, says that he is President of Orange Community Housing and Land Trust, Inc., a North Carolina corporation, and that by authority duly given and as the act of the corporation, the foregoing instrument was signed by him on behalf of the corporation. Witness my hand and notarial seal, this the day of , 2006. Notary Public My commission expires: Exhibit A Property Description Exhibit B DEVELOPMENT AGREEMENT Exhibit C (Place Ground Lease here)